NOTICE: The text below was created automatically and may contain errors and differences from the contract's original PDF file. Learn more here
PRODUCTION SHARING CONTRACT
BETWEEN
THE REPUBLIC OF EQUATORIAL GUINEA
AND
GUINEA ECUATORIAL DE PETROLEOS
AND
[THE COMPANY]
FOR
BLOCK "•"
TABLE OF CONTENTS
ARTICLE 1 - DEFINITIONS AND SCOPE ................................................................................... 2
ARTICLE 2 - EXPLORATION PERIOD AND RELINQUISHMENTS ............................................ 7
ARTICLE 3 - EXPLORATION WORK OBLIGATIONS .............................................................. 10
ARTICLE 4 - ANNUAL WORK PROGRAMS AND BUDGETS .................................................. 12
ARTICLE 5 - APPRAISAL OF A DISCOVERY AND PRODUCTION PERIOD ........................... 14
ARTICLE 6 - CONDUCT OF PETROLEUM OPERATIONS ....................................................... 17
ARTICLE 7 - ROYALTIES, RECOVERY OF PETROLEUM OPERATIONS COSTS, AND
DISTRIBUTION OF PRODUCTION ........................................................................................... 25
ARTICLE 8 - PARTICIPATION INTERESTS ............................................................................. 27
ARTICLE 9 - TAXATION ........................................................................................................... 28
ARTICLE 10 - VALUATION OF CRUDE OIL ............................................................................. 28
ARTICLE 11 - BONUSES AND SURFACE RENTALS .............................................................. 30
ARTICLE 12 - OBLIGATION TO SUPPLY DOMESTIC MARKET ............................................. 32
ARTICLE 13 - NATURAL GAS .................................................................................................. 32
ARTICLE 14 - CUSTOMS REGULATIONS ............................................................................... 35
ARTICLE 15 - FOREIGN CURRENCY ...................................................................................... 37
ARTICLE 16 - BOOKS, ACCOUNTS, AUDITS AND PAYMENTS ............................................. 38
ARTICLE 17 - TRANSFER, ASSIGNMENT AND CHANGE OF CONTROL .............................. 39
ARTICLE 18 - INDEMNIFICATION, LIABILITY AND INSURANCE ........................................... 41
ARTICLE 19 - TITLE OF GOODS, EQUIPMENT AND DATA .................................................... 42
ARTICLE 20 - CONFIDENTIALITY ........................................................................................... 43
ARTICLE 21 - TERMINATION ................................................................................................... 44
ARTICLE 22 - UNITIZATION ..................................................................................................... 46
ARTICLE 23 - LOCAL CONTENT AND SOCIAL PROGRAMS ................................................. 46
ARTICLE 24 - DECOMMISSIONING ......................................................................................... 47
ARTICLE 25 - APPLICABLE LAW ............................................................................................ 49
ARTICLE 26 - RESOLUTION OF CONFLICTS AND ARBITRATION ........................................ 49
ARTICLE 27 - FORCE MAJEURE ............................................................................................. 51
ARTICLE 28 - ASSISTANCE AND NOTICES............................................................................ 52
ARTICLE 29 - MISCELLANEOUS ............................................................................................. 53
ARTICLE 30 - INTERPRETATION ............................................................................................ 54
ARTICLE 31 - EFFECTIVE DATE ............................................................................................. 55
ANNEX A - CONTRACT AREA .......................................................................................... 57
ANNEX B - MAP OF THE CONTRACT AREA .................................................................... 58
ANNEX C - ACCOUNTING PROCEDURE ......................................................................... 59
ANNEX D - PARENT COMPANY GUARANTEE ............................................................... 78
THIS PRODUCTION SHARING CONTRACT is dated this [insert day] day of [insert
month] 200●
BETWEEN:
(1)
THE REPUBLIC OF EQUATORIAL GUINEA (hereinafter referred to as the
State), represented for the purposes of this Contract by the Ministry of Mines,
Industry and Energy, represented for purposes of its execution by His
Excellency Mister ____________
, the Minister;
(2)
GUINEA ECUATORIAL DE PETRÓLEOS (hereinafter referred to as the
National Company), acting in its own name and legal right for the purposes of
this Contract and represented for purposes of its execution by Don
_______________ , in his capacity as Director General; and
(3)
[INSERT NAME], a company organized and existing under the laws of [insert
jurisdiction], under company registration number [insert number] and having
its registered office at [insert address] (hereinafter referred to as [the
Company]), represented for the purposes of this Contract by [insert name], in
his capacity as [insert position].
RECITALS:
(A)
WHEREAS, all Hydrocarbons existing within the territory of the Republic of
Equatorial Guinea, as set forth in the Hydrocarbons Law, are national resources
owned exclusively by the State;
(B)
WHEREAS, the State wishes to promote the development of Hydrocarbon
deposits within the Contract Area and the Contractor desires to associate itself
with the State with a view to accelerating the Development and Production of
Hydrocarbons within the Contract Area;
(C)
WHEREAS, the Contractor has the financial ability, technical competence and
professional skills necessary to carry out Petroleum Operations in accordance
with this Contract and good oil field practices; and
(D)
WHEREAS, the Parties desire to enter into this Contract in accordance with the
Hydrocarbons Law, which allows for agreements to be entered into between the
State and foreign investors in the form of a production sharing contract, through
direct negotiation or by international public tender.
NOW THEREFORE, in consideration of the undertakings and mutual covenants
contained herein, the Parties agree as follows:
1
ARTICLE 1 - DEFINITIONS AND SCOPE
1.1
Definitions
Except where the context otherwise indicates or as defined in the Hydrocarbons
Law or Petroleum Regulations, the following words and expressions shall have
the following meanings:
Accounting Procedure means the accounting procedure set forth in Annex C.
Administrative Operator means the National Company designated as such
under the Joint Operating Agreement.
Affiliated Company or Affiliate of any specified Person means any other
Person directly or indirectly Controlling or Controlled by or under direct
or indirect common Control of such Person.
Annual Budget means the expenditure of the Contractor with respect to an
Annual Work Program.
Appraisal Well means a Well drilled following a Discovery, with the objective of
delimiting and mapping the reservoir, and also to estimate the quantity
of recoverable Hydrocarbons.
Associated Natural Gas means all Natural Gas produced from a reservoir the
predominant content of which is Crude Oil and which is separated from
Crude Oil in accordance with generally accepted international petroleum
industry practice, including free gas cap, but excluding any liquid
Hydrocarbons extracted from such gas either by normal field separation,
dehydration or in a gas plant.
Barrel means a quantity or unit of Crude Oil equal to 158.9874 liters (forty-two
(42) United States gallons) at a temperature of fifteen point five six
degrees (15.56°) Centigrade (sixty degrees (60°) Fahrenheit) and at one
(1) atmosphere of pressure.
Business Day means a day on which the banks are generally open for
business in Equatorial Guinea and [insert jurisdiction].
Calendar Year or Year means a period of twelve (12) months commencing on
1 January and ending on the following 31 December of the same year
according to the Gregorian Calendar.
CIF has the meaning set out in the publication of the International Chamber of
Commerce, INCOTERMS 2000.
Commercial Discovery means a Discovery that the Contractor has determined
to be economically viable and so submits a Development and
Production Plan for such Discovery for the approval of the Ministry.
Contract means this production sharing contract, including its Recitals and
Annexes.
Contract Area or Area means the geographic area within the territory of
Equatorial Guinea, which is the subject of this Contract. Such Contract
Area shall be described in Annex A and illustrated in Annex B, as it may
be changed by relinquishments of the Contractor in accordance with this
Contract.
2
Contract Year means a period of twelve (12) consecutive months according to
the Gregorian calendar, counted from the Effective Date of this Contract
or from the anniversary of such Effective Date.
Contractor means [the Company] and the National Company.
Control, when used with respect to any specified Person, means the power to
direct, administer and dictate policies of such Person through the
ownership of a percentage of such Person's equity sufficient to hold a
majority of voting rights in an ordinary shareholders meeting. The terms
Controlling and Controlled have meanings correlative to the foregoing.
Cost Recovery Oil has the meaning ascribed to it in Article 7.2.1.
Crude Oil means Hydrocarbons which are produced at the wellhead in a liquid
state at atmospheric pressure including asphalt and ozokerites, and the
liquid Hydrocarbons known as condensate and/or Natural Gas liquids
obtained from Natural Gas by condensation or extraction through field
separation units.
Delivery Point means that point located within the jurisdiction of Equatorial
Guinea at which Hydrocarbons reach (i) the inlet flange at the FOB
export vessel, (ii) the loading facility metering station of a pipeline or (iii)
such other point within the jurisdiction of Equatorial Guinea as may be
agreed by the Parties.
Development and Production Area means an area within the Contract Area
encompassing the geographical extent of a Commercial Discovery
subject to a Development and Production Plan in accordance with
Article 5.5.
Development and Production Costs means all costs, expenses and liabilities
incurred by the Contractor in connection with Development and
Production Operations in a Development and Production Area,
excluding all Exploration Costs incurred in the Development and
Production Area prior to the establishment of any Field, as determined in
accordance with this Contract and the Hydrocarbons Law.
Development and Production Operations means all operations, other than
Exploration Operations, conducted to facilitate the Development and
Production of Hydrocarbons from the Contract Area to the Delivery
Point, but excluding the refining and distribution of Hydrocarbon
products.
Development and Production Plan has the meaning ascribed to it in Article
5.5.1. Platts means Platts Crude Oil MarketWire.
Development Well means a Well, other than an Exploration Well or an
Appraisal Well, drilled with the purpose of producing or improving the
Production of Hydrocarbons, including Exploration Wells and Appraisal
Wells completed as production or injection Wells.
Discovery means the finding by the Contractor of Hydrocarbons whose
existence within the Contract Area was not known prior to the Effective
Date or Hydrocarbons within the Contract Area which had not been
declared a Commercial Discovery prior to the Effective Date and which
are measurable by generally accepted international petroleum industry
practices.
3
Dollars or $ means the legal tender of the United States of America.
Effective Date means the date of receipt by the Contractor of the ratification by
the State of this Contract.
Equatorial Guinea means the Republic of Equatorial Guinea.
Exploration Costs means all costs, expenses and liabilities incurred by the
Contractor in connection with Exploration Operations in the Contract
Area, as determined in accordance with this Contract and the
Hydrocarbons Law.
Exploration Operations include geological and geophysical studies, aerial
mapping, investigations relating to subsurface geology, stratigraphic test
drilling, Exploration Wells, Appraisal Wells and related activities such as
drill site preparation, surveying and all work connected therewith that is
conducted in relation to the Exploration for and Appraisal of
Hydrocarbon deposits in the Contract Area.
Exploration Periods means the Initial Exploration Period, an Extension Period
and any further extensions thereof.
Exploration Well means any Well whose sole objective is to verify the
existence of Hydrocarbons or to study all the necessary elements that
might lead to a Discovery.
Extension Period means the First Extension Period and the Second Extension
Period individually and/or jointly, as the context may require.
Field means a Discovery or an aggregation of Discoveries that is established as
a Field in accordance with Article 5 and can be developed commercially
after taking into account all pertinent operational, economic and financial
data collected during the performance of the Appraisal work program or
otherwise, in accordance with generally accepted international
petroleum practices. A Field may consist of a Hydrocarbon reservoir or
multiple Hydrocarbon reservoirs all grouped on or related to the same
individual geological structural or statigraphic conditions. All deposits
superimposed, adjacent to or underlying a Field in the Contract Area
shall form part of the said Field.
First Exploration Sub-Period means the first [insert number] Contract
Year(s) of the Initial Exploration Period.
First Extension Period means the period of one (1) Contract Year
commencing immediately after the conclusion of the Initial Exploration
Period.
FOB has the meaning set out in the publication of the International Chamber of
Commerce, INCOTERMS 2000.
Gross Revenues means the total income from sales of Total Disposable
Production plus the equivalent monetary value of any other disposal of
Total Disposable Production from the Contract Area during any
Calendar Year.
Hydrocarbons means all natural organic substances composed of carbon and
hydrogen, including Crude Oil and Natural Gas that may be found and
extracted from, or otherwise produced and saved from the Contract
Area.
4
Hydrocarbons Law means Decree-Law No. 8/2006 dated 3 November 2006 of
Equatorial Guinea.
Income Tax means that tax levied on the each of the Parties comprising the
Contractor and all other applicable Persons pursuant to and in
accordance with the Tax Law.
Initial Exploration Period means a period of [insert number] Contract Year(s)
from the Effective Date, subdivided into two sub-periods of [insert
number] Contract Year(s) each.
Joint Operating Agreement or JOA means the joint operating agreement that
regulates the internal relations of the Parties comprising the Contractor
for the conduct of Petroleum Operations in the Contract Area.
LIBOR means the interest rate at which Dollar deposits of six (6) months
duration are offered in the London Inter Bank Market, as published in the
Financial Times of London. The applicable LIBOR rate for each month
or part thereof within an applicable interest period shall be the interest
rate published in the Financial Times of London on the last Business
Day of the immediately preceding calendar month. If no such rate is
quoted in the Financial Times of London during a period of five (5)
consecutive Business Days, another rate (for example, the rate quoted
in the Wall Street Journal) chosen by mutual agreement between the
Ministry and the Contractor will apply.
Market Price means the FOB price for Crude Oil calculated in accordance with
Article 10.
Material Contract means a contract with an Affiliate and/or a contract for the
provision of goods and/or services having a value exceeding [insert
amount] Dollars ($[insert amount]).
Maximum Efficient Production Rate means the maximum efficient production
rate of Hydrocarbons from a Field, that does not damage reservoir
formations and does not cause excessive decline or loss of reservoir
pressure in accordance with good oil field practice and as agreed in
accordance with Article 6.4.
Ministry means the Ministry of Mines, Industry and Energy of Equatorial
Guinea, the entity responsible for supervising Petroleum Operations in
coordination with other Government bodies within the respective areas
of their competence, and any successor.
National Company's Participation Interest means the Participation Interest of
the National Company as set forth in Article 1.3.
Natural Gas means those Hydrocarbons that, at atmospheric conditions of
temperature and pressure, are in a gaseous state including dry gas, wet
gas and residual gas remaining after extraction, treatment, processing,
or separation of liquid Hydrocarbons from wet gas, as well as gas or
gases produced in association with liquid or gaseous Hydrocarbons.
Net Crude Oil has the meaning ascribed to it in Article 7.3.
Net Natural Gas has the meaning ascribed to in Article 13.3.5.
Participation Interest means for each Party comprising the Contractor, the
undivided percentage share of such Party in the rights and obligations
under this Contract, as is specified in Article 1.3.
5
Parties or Party means the parties or a party to this Contract, as the context
may require.
Person means any individual, firm, company, corporation, society, trust,
foundation, government, state or agency of the state or any association
or partnership (whether or not having separate legal personality) or two
or more of these.
Petroleum Operations means all operations related to Exploration,
Development, Production, transportation, storage, conservation,
decommissioning, sale and/or other disposal of Hydrocarbons from the
Contract Area to the Delivery Point and any other work or activities
necessary or ancillary to such operations; these operations and activities
shall be carried out in accordance with this Contract and the
Hydrocarbons Law and shall not include transport outside of Equatorial
Guinea.
Petroleum Operations Costs means Exploration Costs and/or Development
and Production Costs (as the context may require) incurred by the
Contractor in the carrying out of Petroleum Operations, as determined in
accordance with this Contract and the Accounting Procedure.
Petroleum Regulations means all regulations promulgated by the Ministry
pursuant to the Hydrocarbons Law.
Quarter means a period of three (3) consecutive months beginning on 1
January, 1 April, 1 July or 1 October and ending on 31 March, 30 June,
30 September or 31 December, respectively.
Reserve Fund has the meaning ascribed to it in Article 24.3.1.
Royalties means an entitlement of the State over Hydrocarbons produced and
saved from the Contract Area, and not utilized in Petroleum Operations,
based on percentages calculated as a function of the daily rate of the
Total Disposable Production as determined in accordance with Article
7.1.
Second Exploration Sub-Period means the final [insert number] Contract
Year(s) of the Initial Exploration Period.
Second Extension Period means the period of one (1) Contract Year
commencing immediately after the end of the First Extension Period.
Tax Law means Decree-Law No. 4/2004 dated 28 October 2004 of Equatorial
Guinea, and any law that amends it or replaces it.
Technical Operator shall be [the Company], as approved by the Ministry and
designated as such under the Joint Operating Agreement.
Total Disposable Production means all Hydrocarbons produced and saved
from a Development and Production Area less the quantities used for
Petroleum Operations.
Unassociated Natural Gas means all gaseous Hydrocarbons produced from
Natural Gas reservoirs, and includes wet gas, dry gas and residual gas
remaining after the extraction of liquid Hydrocarbons from wet gas.
Well means any opening in the ground or seabed made or being made by
drilling or boring, or in any other manner, for the purpose of exploring
and/or discovering, evaluating or producing Crude Oil or Natural Gas, or
6
for the injection of any fluid or gas into an underground formation other
than a seismic hole.
1.2
Scope
1.2.1
This Contract is a production sharing contract awarded pursuant to Chapter IV
of the Hydrocarbons Law. In accordance with the provisions of this Contract and
the Hydrocarbons Law, the Ministry shall be responsible for supervising
Petroleum Operations in the Contact Areas.
1.2.2
The State grants to the Contractor the sole and exclusive right and charge of
conducting all Petroleum Operations in the Contract Area during the term of this
Contract. In consideration of this, the Contractor shall:
(a)
be responsible to the State as an independent contractor, for the
execution of the Petroleum Operations in accordance with the
provisions of this Contract and the Hydrocarbons Law;
(b)
provide all funds, machinery, equipment, technology and
personnel prudent and necessary to conduct Petroleum
Operations; and
(c)
diligently, with due regard to good oil field practice, perform at its
exclusive responsibility and risk all investments and contractual
obligations necessary for conducting Petroleum Operations in
accordance with this Contract.
1.2.3
All Petroleum Operations Costs shall be recoverable and/or deductible for tax
purposes in the manner set forth in this Contract and the Hydrocarbons Law.
1.2.4
During the term of this Contract, the total Production achieved as a
consequence of Petroleum Operations shall be shared between the Parties in
accordance with Article 7.
1.3
Participation Interests
On the Effective Date the Participation Interests of the Parties comprising the
Contractor are as follows:
[The Company]
[insert number]%
The National Company
[insert number]%
Total
100%
ARTICLE 2 - EXPLORATION PERIOD AND RELINQUISHMENTS
2.1
Initial Exploration Period
As of and from the Effective Date, the Contractor is authorized to conduct
Exploration Operations in the Contract Area during the Initial Exploration Period.
2.2
Extension Periods
2.2.1
Upon the fulfillment by the Contractor of its Exploration obligations set forth in
Articles 3.1.1 and 3.1.2 with respect to the Initial Exploration Period, the
7
Contractor may request up to two (2) extensions of the Initial Exploration
Period.
2.2.2
For each Extension Period, the Contractor shall file a request with the Ministry
at least two (2) months prior to the expiry of the Initial Exploration Period, or as
the case may be, the First Extension Period. The Ministry shall not
unreasonably withhold or delay the granting of such extension; provided that the
Contractor has complied with all of its obligations in the Initial Exploration Period
and the First Extension Period, as applicable, and shall not be otherwise in
breach of this Contract.
2.2.3
Each request for an extension shall be accompanied by a map specifying the
Contract Area proposed to be retained by the Contractor, along with a report
specifying any work performed in the proposed relinquished area since the
Effective Date and the results obtained therefrom.
2.2.4
If upon expiry of the Initial Exploration Period, or of any Extension Period, any
Appraisal work program with respect to a Discovery is still under progress, the
Contractor shall be entitled to an additional extension of the then current
Exploration Period necessary to complete the work in progress. Furthermore,
where Appraisal work has not yet been completed by the Contractor at the time
at which a relinquishment contemplated by Article 2.4 is due, the requirement to
relinquish shall be suspended until such time that the Contractor completes the
said Appraisal work, commerciality is determined and, if applicable, the related
establishment of a Field is approved or denied. Any additional extension
granted under this Article 2.2.4 shall not exceed one (1) Contract Year, or such
longer period as may be approved by the Ministry, plus the period of time
established under Article 5 necessary for the evaluation of a marketing plan, the
preparation of a Development and Production Plan and the Ministry's response.
2.2.5
In such event, the Contractor shall file a request for an extension with the
Ministry at least two (2) months prior to the expiry of the current Initial
Exploration Period or Extension Period, as applicable.
2.3
Termination
Should the Contractor decide:
(a)
not to extend the Initial Exploration Period and no Field has been
established during such period; or
(b)
to extend the Initial Exploration Period and no Field has been
established during an Extension Period or any additional
extension thereof,
this Contract shall automatically terminate.
2.4
Mandatory Relinquishments
2.4.1
The Contractor must relinquish to the State forty percent (40%) of the initial
surface area of the Contract Area by the end of the Initial Exploration Period,
twenty-five percent (25%) of the remaining area by the end of the First
Extension Period, and the remainder of the Contract Area by the end of the
Second Extension Period, or at the end of the Initial Exploration Period or the
First Extension Period, if no further extension is requested by the Contractor. To
determine the area or areas which the Contractor shall relinquish, the following
areas shall be excluded for the purposes of such calculation:
8
2.4.2
(a)
areas designated as an Appraisal Area;
(b)
Development and Production Areas;
(c)
areas for which the approval of a Development and Production
Plan is pending, until finally decided;
(d)
the area of any Field, including any Field which may be subject to
unitization pursuant to Article 22; and
(e)
any area reserved for a possible Unassociated Natural Gas
Appraisal in relation to which the Contractor is engaged in
discussions with the Ministry in accordance with Article 13.1.
Upon expiry of the applicable final extension period indicated in Article 2.2, and
subject to the provisions of Article 2.2.4, the Contractor shall relinquish the
remainder of the Contract Area, with the exception of:
(a)
Development and Production Areas;
(b)
those areas for which an application for a Development and
Production Area is pending, until finally decided;
(c)
the area of any Field, including any Field which may be subject to
unitization pursuant to Article 22; and
(d)
any area reserved for a possible Unassociated Natural Gas
Appraisal in relation to which the Contractor is engaged in
discussions with the Ministry in accordance with Article 13.
2.5
Voluntary Relinquishments
2.5.1
Subject to the Contractor's obligations under Article 24 and the Hydrocarbons
Law, the Contractor may at any time notify the Ministry upon three (3) months
prior notice that it relinquishes all of its rights over all or any part of the Contract
Area.
2.5.2
In no event shall any voluntary relinquishment by the Contractor of rights over
all or any part of the Contract Area reduce the Exploration obligations of the
Contractor set forth in Article 3.
2.6
Relinquishments Generally
2.6.1
No relinquishment made in accordance with Articles 2.4 or 2.5 shall relieve the
Contractor from its obligation to pay surface rentals accrued or make payments
due and payable as a result of Petroleum Operations conducted up to the date
of relinquishment.
2.6.2
The Contractor shall, in accordance with good oil field practice, propose the
geographic location of the portion of the Contract Area that it proposes to retain,
and which shall have a continuous geometric shape going from North to South
and East to West delimited as a minimum by one minute (1') of latitude or
longitude or by natural boundaries and such area shall also be subject to the
approval of the Ministry.
9
ARTICLE 3 - EXPLORATION WORK OBLIGATIONS
3.1
Minimum Work Program
During the Exploration Period, the Contractor undertakes to carry out the
following minimum work program:
3.1.1
During the First Exploration Sub-Period, the Contractor must:
(a)
obtain, under license from the Ministry, all existing 2D and 3D
seismic data and Well data at a purchase price of [insert
amount] Dollars ($[insert amount]) and obtain from GESeis all
existing 3D seismic and Seabed Logging (SBL) data at a
purchase price of [insert amount] Dollars ($[insert amount]),
and the Contractor shall undertake to interpret such information;
(b)
reprocess [insert number] kilometers of existing 2D seismic
data and [insert number] kilometers of 3D seismic data; and
(c)
acquire [insert number] kilometers of new 3D seismic data.
All costs of data acquisition (including escalation fees) shall be cost
recoverable. The minimum expenditure for this period shall be [insert amount]
Dollars ($[insert amount]).
3.1.2
During the Second Exploration Sub-Period, the Contractor must drill a minimum
of [insert number] Exploration Well[s] to a minimum depth of [insert number]
meters below the seabed. The minimum expenditure for this period shall be
[insert amount] Dollars ($[insert amount]).
3.1.3
If the Contractor elects to enter the First Extension Period, the Contractor must
drill a minimum of [insert number] Exploration Well[s] to a minimum depth of
[insert number] meters below the seabed. The minimum expenditure for this
period shall be [insert amount] Dollars ($[insert amount]).
3.1.4
If the Contractor elects to enter the Second Extension Period, the Contractor
must drill a minimum of [insert number] Exploration Well[s] to a minimum
depth of [insert number] meters below the seabed. The minimum expenditure
for this period shall be [insert amount] Dollars ($[insert amount]).
However, if the Contractor has drilled more than the minimum number of
Exploration Wells required of it under any of Articles 3.1.1, 3.1.2 or 3.1.3, then
its obligation under this Article 3.1.4 shall be reduced to [insert number]
Exploration Well[s].
3.2
Minimum Depth of Wells
3.2.1
Each Exploration Well set forth above must be drilled to the minimum depth
specified above or to a lesser depth if authorized by the Ministry in accordance
with this Article or if discontinuing drilling is justified by one of the following
reasons:
(a)
the economic basement is encountered at a depth less than the
stipulated minimum contractual depth;
(b)
continued drilling is clearly dangerous because of abnormal
pressure in the formation;
10
(c)
rock formations are encountered, the hardness of which makes it
impracticable to continue drilling with appropriate equipment; or
(d)
Hydrocarbon bearing formations are encountered that require the
installation of protective casings which excludes the possibility of
reaching the minimum contractual depth.
3.2.2
For the purposes of Article 3.2.1, economic basement means any stratum in
and below which the geological structure or physical characteristics of the rock
sequence do not have the properties necessary for the accumulation of
Hydrocarbons in commercial quantities and which also reflects the maximum
depth at which any accumulation of this type can be reasonably expected.
3.3
Cessation of Drilling
In respect of Article 3.2.1(a) and to the extent practicable where a prudent
operator would immediately cease drilling operations, the Contractor shall
obtain the approval of the Ministry prior to the interruption or cessation of any
drilling. The Ministry shall respond as soon as practicable and in any event
within three (3) Business Days counted from the date of receipt of such request.
The granting of such approval may not be unreasonably withheld or delayed,
provided that the Ministry is in receipt of sufficient information to enable it to
make an informed decision.
3.4
Substitute Wells
If any obligatory Exploration Well is abandoned due to insurmountable technical
problems as set out in Article 3.2.1 (b), (c) and (d) and, at the time of such
abandonment, the Exploration Costs for such Well have equaled or exceeded
[insert amount] Dollars ($[insert amount]), for all purposes of this Contract,
the Contractor shall be deemed to have fulfilled the minimum work obligations
for the relevant period. If any obligatory Exploration Well is abandoned due to
insurmountable technical problems, and if at the time of such abandonment, the
Exploration Costs for such Well are less than [insert amount] Dollars ($[insert
amount]) then the Contractor shall have the option to either:
3.5
(a)
drill a substitute Exploration Well at the same or another location
to be agreed with the Ministry; or
(b)
pay the Ministry an amount equal to the difference between
[insert amount] Dollars ($[insert amount]) and the amount of
Exploration Costs actually spent in connection with such
Exploration Well.
Provision of Guarantee
On or prior to the Effective Date, each of the Parties comprising the Contractor
(other than the National Company) shall provide to the State, at the sole
discretion of the Ministry, either (i) a parent company guarantee in the form set
forth in Annex D from a company acceptable to the Ministry or (ii) an irrevocable
standby letter of credit from a first class international financial institution
acceptable to the Ministry in the amount of [insert amount] Dollars ($[insert
amount]), which corresponds to the minimum expenditure obligations of the
Contractor under this Contract, and which shall remain valid and effective for six
(6) months after the end of the Initial Exploration Period, any Extension Period
11
and any additional extension thereof, as applicable. If the Parties comprising the
Contractor (other than the National Company) fail to deliver to the Ministry the
required guarantee by or on the Effective Date, this Contract shall be
considered null and void without any further procedure or notice.
3.6
Participation Interest of the National Company
For the purposes of this Article 3 any expenditure of the Parties comprising the
Contractor (other than the National Company) under Article 8.2 shall not be
treated as an expenditure for the purpose of satisfying the minimum expenditure
obligations set out herein.
ARTICLE 4 - ANNUAL WORK PROGRAMS AND BUDGETS
4.1
Submission of Annual Work Program
No later than ninety (90) days prior to the beginning of each Calendar Year, or
for the first Calendar Year no later than sixty (60) days after the Effective Date,
the Contractor shall prepare and submit for approval by the Ministry a detailed
and itemized Annual Work Program divided into Quarters, along with the
corresponding Annual Budget for the Contract Area setting forth the Petroleum
Operations the Contractor proposes to carry out during such Calendar Year.
The Annual Budget shall be presented in the official format of the Ministry.
4.2
Form and Approval of Annual Work Program
Each Annual Work Program and corresponding Annual Budget shall be broken
down into the various Exploration Operations and, as applicable, the Appraisal
operations for each Appraisal Area and the Development and Production
Operations for each Development and Production Area. The Ministry may
propose amendments or modifications to the Annual Work Program and
corresponding Annual Budget, by giving notice to the Contractor and including
reasons for such amendments or modifications, within sixty (60) days following
receipt of such Annual Work Program and Annual Budget. In such event the
Ministry and the Contractor shall meet as soon as possible to review the
amendments or modifications proposed by the Ministry and establish by mutual
agreement the Annual Work Program and corresponding Annual Budget. The
parts of the Annual Work Program for which the Ministry does not require
amendment or modification will be deemed approved and must be completed
by the Contractor within the stated time period, provided they may be
undertaken on an individual basis. With respect to the parts of the Annual Work
Program for which the Ministry proposes any amendment or modification, the
date of approval of the Annual Work Program and corresponding Annual
Budget shall be the date on which the Ministry and the Contractor reach the
aforementioned mutual agreement. In the event the Ministry and the Contractor
do not reach an agreement regarding the amendments and modifications
proposed by the Ministry before the end of the Calendar Year in which the
Annual Work Plan and corresponding Annual Budget were submitted, the
Contractor shall continue operating pursuant to the most recent Annual Work
Plan and corresponding Annual Budget approved by the Ministry until a mutual
agreement is reached.
12
4.3
Conduct of Petroleum Operations
The Contractor shall diligently and properly perform each operation included in
an approved Annual Work Program in accordance with the terms of this
Contract and the Hydrocarbons Law.
4.4
Overexpenditures
4.4.1
It is acknowledged by the Ministry and the Contractor that the technical results
acquired as work progresses or the occurrence of certain unforeseen changes
in circumstances may justify modifications to an approved Annual Work
Program and corresponding Annual Budget. In such circumstances, the
Contractor shall promptly notify the Ministry of the proposed modifications. Such
modifications are subject to review and approval by the Ministry within sixty (60)
days after receipt of such notice. Failure of the Ministry to approve or reject such
proposed modifications within such sixty (60) day period shall be deemed to be
an approval of such proposed modifications. Notwithstanding the foregoing and
in no event shall the Contractor incur any expenditure which exceeds an
approved Annual Budget by more than five percent (5%) without the prior
approval of the Ministry; otherwise such excess expenditures shall not be
recoverable as a Petroleum Operations Cost or deductible for tax purposes.
4.4.2
At such time that the Contractor reasonably believes that the limits of an Annual
Budget will be exceeded, the Contractor shall promptly notify the Ministry and
shall provide the Ministry with full details of such overexpenditures, including
reasons therefor.
4.4.3
The limitations set out in this Article 4.4 shall be without prejudice to the
Contractor’s right to make expenditures in the event of an emergency or
accident requiring urgent action under Article 4.5.
4.4.4
Save as otherwise provided in Article 4.5, should the Contractor incur any
expenditure whose program and budget has not been approved within an
Annual Work Program and corresponding Annual Budget or any amendment
thereto approved by the Ministry, then such expenditure shall not be
recoverable by the Contractor as a Petroleum Operations Cost or be deductible
for tax purposes.
4.5
Emergency or Accident
4.5.1
In the event of an emergency or accident requiring urgent action, the Contractor
shall take all steps and measures as may be prudent and necessary in
accordance with good oil field practice for the protection of its interests and
those of the State and the property, life and health of other Persons, the
environment and the safety of Petroleum Operations. The Contractor shall
promptly inform the Ministry of such emergency or accident.
4.5.2
All of the related costs incurred by the Contractor in accordance with this Article
4.5 shall be recoverable as Petroleum Operations Costs in accordance with this
Contract. Notwithstanding the foregoing, all costs incurred by the Contractor in
the cleaning up of pollution or damage to the environment caused by the
negligence or willful misconduct of the Contractor, its subcontractors or any
Person acting on its or their behalf shall not be recoverable as a Petroleum
13
Operations Cost.
ARTICLE 5 - APPRAISAL OF A DISCOVERY AND PRODUCTION PERIOD
5.1
Notification of Discovery
If the Contractor discovers Hydrocarbons in the Contract Area it shall notify the
Ministry as soon as possible, but not later than thirty (30) days after the date of
such Discovery. This notice shall include all relevant information in accordance
with generally accepted practice of the international petroleum industry
including particulars of any production testing program which the Contractor has
carried out or proposes to carry out during drilling operations.
5.2
Appraisal Work Program
5.2.1
If the Contractor considers that the Discovery merits Appraisal it shall diligently
submit to the Ministry a detailed Appraisal work program and corresponding
budget no later than six (6) months following the date on which the Discovery
was notified in accordance with Article 5.1. The Appraisal work program,
corresponding budget and designated Appraisal Area are subject to the review
and approval of the Ministry in accordance with the procedures set forth in
Article 4.
5.2.2
The draft Appraisal work program shall specify the estimated size of the
Hydrocarbon reserves of the said Discovery, the area proposed to be
designated as the Appraisal Area and shall include all seismic, drilling, testing
and Appraisal operations necessary to carry out an appropriate Appraisal of the
Discovery. The Contractor shall diligently undertake the approved Appraisal
work program, it being understood that the provisions of Article 4.4 shall apply
to such program.
5.2.3
The duration of the Appraisal work program shall not exceed twenty-four (24)
months for Crude Oil and in the case of Natural Gas the duration of the
Appraisal work program shall be determined in accordance with the provisions
of Article 13, unless as otherwise approved by the Ministry, such approval not to
be unreasonably withheld or delayed.
5.3
Submission of Appraisal Report
5.3.1
Within six (6) months following completion of the Appraisal work program and in
any event no later than thirty (30) days prior to the expiry of the Initial
Exploration Period, or the First Extension Period or the Second Extension
Period, including any additional extension in accordance with the provisions of
Article 2.2, as may be the case, the Contractor shall submit to the Ministry a
detailed report giving all the technical and economic information associated with
the Discovery so appraised and which shall confirm, in the Contractor's opinion,
whether such Discovery is a Commercial Discovery.
5.3.2
The above-referred report shall include geological and petrophysical
characteristics of the Discovery, estimated geographical extent of the
Discovery, results of the production tests yielded by the formation and the
14
preliminary economic study with respect to the exploitation of the Discovery.
5.4
Determination of Commerciality
For the purposes of Article 5.3, the Contractor shall determine whether it
considers that a Discovery or aggregation of Discoveries can be developed
commercially. The commercial viability of the Discovery or aggregation of
Discoveries shall be determined after consideration of all pertinent operating,
economic and financial data collected during the performance of the Appraisal
work program and otherwise, including Crude Oil and Natural Gas recoverable
reserves, sustainable Production levels and all other relevant economic factors,
according to generally accepted international petroleum industry practice.
5.5
Submission and Approval of Development and Production Plan
5.5.1
If the Contractor deems the Discovery or aggregation of Discoveries to be a
Field it shall submit for the approval of the Ministry a development and
production plan (the Development and Production Plan) for such Discovery or
aggregation of Discoveries within twelve (12) months following the remittance of
the report referred to in Article 5.3.
5.5.2
The Ministry may propose amendments or modifications to the aforementioned
Development and Production Plan, and also to the Development and
Production Area subject to such Development and Production Plan, by notice to
the Contractor within ninety (90) days following receipt of the relevant plan.
Such notification shall set out the reasons for the amendments or modifications
proposed by the Ministry. In such event the Ministry and the Contractor shall
meet as soon as possible to review the proposed amendments or modifications
of the Ministry and establish by mutual agreement the Development and
Production Plan.
5.5.3
If the Contractor and the Ministry do not reach a written agreement within one
hundred eighty (180) days following the submission of amendments and
modifications by the Ministry, or the Ministry notifies the Contractor that it does
not approve the establishment of a Field, the Field shall not be established and
any extension granted under Article 2.2.4 with respect to the Discovery or
aggregation of Discoveries shall expire.
5.6
Modifications to Development and Production Plan
5.6.1
When the results obtained during Development and Production Operations
require certain modifications to the Development and Production Plan, such
plan may be modified using the same procedure provided for with respect to the
initial approval thereof. Subject to Article 4.4, the Contractor may not incur any
expenditure which exceeds the approved Development and Production Plan
without the prior approval of the Ministry; if prior approval is not obtained, such
excess expenditures will not be recoverable by the Contractor as Petroleum
Operations Costs or deductible for tax purposes.
5.6.2
During a period of Development and Production, the Contractor may propose
to the Ministry revisions to the Development and Production Plan at any time
that additional Development and Production Operations are under
consideration. Such revisions shall be submitted for approval by the Ministry,
15
using the same procedure provided for with respect to the initial approval
thereof.
5.7
Number of Fields
If the Contractor discovers more than one (1) Field in the Contract Area which
are not overlying, adjacent to or underlying an existing Field, each of them shall
be the subject of a separate Development and Production Plan.
5.8
Extension of Field beyond Contract Area
5.8.1
If, during work performed after approval of a Development and Production Plan,
it appears that the geographical extent of a Field is larger than the Development
and Production Area designated pursuant to Article 5.5, the Ministry may grant
the Contractor the additional area, on condition that it is included in the Contract
Area in effect at that time, and provided that the Contractor provides supporting
evidence of the existence of the additional area applied for.
5.8.2
In the event that a Field extends beyond the boundaries of the Contract Area as
delimited at any particular time, the Ministry may require the Contractor to
exploit such Field in association with the contractor of the adjacent area in
accordance with Article 22, the Hydrocarbons Law and generally accepted
practice of the international petroleum industry.
5.8.3
When the area proposed to be unitized is not subject to any production sharing
contract, such area shall be the subject of new negotiations between the
Parties, it being understood that any award of an additional area must be in
accordance with the Hydrocarbons Law.
5.9
Commencement and Performance of Development and Production
Operations
5.9.1
The Contractor shall commence Development and Production Operations within
six (6) months from the date of approval of the Development and Production
Plan and shall pursue such operations diligently.
5.9.2
The Contractor undertakes to perform all Development and Production
Operations in accordance with generally accepted practice of the international
petroleum industry, this Contract and the Hydrocarbons Law.
5.10
Duration of Operations
5.10.1
The duration of the Development and Production period during which
the Contractor is authorized to exploit a Field is twenty-five (25) Years from the
date of approval of the Development and Production Plan related to such Field.
5.10.2
The Development and Production period defined above may be
extended for an additional period of five (5) Years with prior approval of the
Ministry, which approval shall not be unreasonably withheld or delayed, if the
Contractor submits a request to this effect to the Ministry at least one (1) Year
prior to its expiry and on the condition that the Contractor has fulfilled all of its
obligations under this Contract and that it can demonstrate that commercial
Production from the Field is still possible after the expiry of the initial
Development and Production period.
16
5.11
Risk and Expense of Contractor
The Contractor undertakes to perform at its own expense and financial risk all
the Petroleum Operations required to place a Field into Production in
accordance with the Development and Production Plan so approved.
5.12
Mandatory Relinquishment
For the duration of the Initial Exploration Period, the Extension Periods and any
additional extension thereof, the Ministry may, provided it gives at least six (6)
months notice, require the Contractor to promptly relinquish, without any
compensation or indemnification, all of its rights over the area encompassing a
Discovery, including all of its rights over Hydrocarbons which may be produced
from such Discovery, if the Contractor:
5.13
(a)
has not submitted, in accordance with Article 5.2, an Appraisal
work program and corresponding budget with respect to such
Discovery within six (6) months following the date on which such
Discovery has been notified to the Ministry; or
(b)
subject to Article 13.1 regarding Unassociated Natural Gas, does
not establish the Discovery as a Field within one (1) Year after
completion of Appraisal work with respect to such Discovery.
Future Operations
In the event of a relinquishment under Article 5.12, the Ministry may perform or
cause to be performed any Petroleum Operations with respect to any Discovery
so relinquished without any compensation or indemnification to the Contractor,
provided, however, that it shall not interfere with the Petroleum Operations
undertaken by the Contractor in the part of the Contract Area retained by the
Contractor, if any. The Ministry shall be permitted to use (free of charge) all
facilities and equipment of the Contractor that are not used for continuing
Petroleum Operations. If requested by the Ministry all continuing operations
shall be undertaken by the Contractor for a fee and on terms to be agreed
between the Ministry and the Contractor.
ARTICLE 6 - CONDUCT OF PETROLEUM OPERATIONS
6.1
Obligations of Contractor
In accordance with generally accepted practice of the international petroleum
industry and the Hydrocarbons Law, the Contractor shall provide all funds
necessary for the conduct of Petroleum Operations in the Contract Area
including the purchase or rental of all facilities, equipment, materials and other
goods required for the performance of such Petroleum Operations. It shall also
supply all technical and operational expertise, including the use of foreign and
national personnel required for implementing Annual Work Programs. The
Contractor shall be responsible for the preparation and implementation of all
Annual Work Programs which shall be performed in accordance with this
Contract, the Hydrocarbons Law and generally accepted practice of the
international petroleum industry.
17
6.2
Joint Operating Agreement
Within forty-five (45) days following the Effective Date, the Contractor shall
provide the Ministry with a draft of the Joint Operating Agreement which shall be
based upon the current model form operating agreement from the Association
of International Petroleum Negotiators (AIPN). The Joint Operating Agreement
and all amendments thereto shall be subject to the prior approval of the
Ministry. The identity of the Technical Operator and any change thereto shall be
subject to the prior approval of the Ministry in accordance with the
Hydrocarbons Law. The National Company shall be appointed as the
Administrative Operator under the Joint Operating Agreement.
6.3
Conduct of Petroleum Operations
The Contractor shall diligently conduct Petroleum Operations in accordance
with this Contract, the Hydrocarbons Law and generally accepted practice of the
international petroleum industry.
6.4
Maximum Efficient Production Rate
The Contractor and the Ministry shall agree on the Production programs before
Production begins in any Field and establish at that time the Maximum Efficient
Production Rate for such Field, and will determine the dates on which such
levels will be reexamined and potentially revised.
6.5
Working Conditions
The Contractor shall provide acceptable working conditions and access to
medical attention and nursing care for all of its local and international personnel
and those of its subcontractors while undertaking Petroleum Operations. The
Contractor shall also provide living accommodation for personnel based on
offshore installations and an additional accommodation allowance in the
remuneration of personnel based onshore.
6.6
Discovery of other Minerals
The Contractor shall promptly notify the Ministry of the discovery of any
minerals or other substances in the Contract Area. If any Persons are granted a
permit or license within the Contract Area for the exploration and exploitation of
any minerals or substances other than Hydrocarbons, the Ministry shall take all
reasonable measures to ensure that the operations of such Persons will not
obstruct the Contractor's Petroleum Operations. The Contractor shall use all
reasonable efforts to avoid any obstruction with such permit holders or
licensees' operations.
18
6.7
Award of Contracts
6.7.1
Subject to Article 23.1, the Contractor shall award all contracts to the best
qualified subcontractor or other Person, including Affiliates of the Contractor, as
determined by cost and ability to perform the contract without the obligation to
tender and without obtaining the approval of the Ministry (which approval shall
be deemed granted under the Hydrocarbons Law), except that before entering
into any Material Contract, the Contractor shall:
(a)
invite tenders for said contract;
(b)
add to such list any Persons who the Ministry requests;
(c)
complete the tender process within a reasonable period of time;
(d)
consider and analyze the details of the bids received;
(e)
prepare and circulate to the Ministry a competitive bid analysis
stating the Contractor’s recommendation as to the Person to
whom the contract should be awarded, the reasons therefor, and
the technical, commercial and contractual terms to be agreed
upon;
(f)
obtain the approval of the Ministry; and
(g)
provide the Ministry with a copy of the final executed contract.
All amendments and/or variations to a Material Contract shall require the prior
approval of the Ministry.
6.7.2
To the extent that the Contractor imports and/or uses any services, materials,
equipment, consumables and other goods from outside of Equatorial Guinea in
contravention of this Article or Article 23.1, or otherwise enters into a contract in
contravention of such Articles, the costs thereof shall not be Petroleum
Operations Costs and shall not be cost recoverable by the Contractor.
6.7.3
The Contractor shall submit to the Ministry along with the Annual Work Program
a list of the types of contracts or agreements for services that the Contractor
foresees entering into during that Year as well as details of those entered into in
the previous Year. In addition, the Contractor shall present to the Ministry
quarterly a detailed list, including the names, addresses and telephone contacts
of the Contractor’s subcontractors and other Persons who have provided goods
or services to the Contractor for the conduct of Petroleum Operations during the
relevant Quarter.
6.8
Inspection of Petroleum Operations
6.8.1
All Petroleum Operations may be inspected and audited by the Ministry at such
intervals as the Ministry deems necessary. The duly commissioned
representatives of the Ministry shall have the right, among others, to monitor
Petroleum Operations and inspect all equipment, facilities and materials relating
to Petroleum Operations, provided that any such inspection shall not unduly
delay or impede Petroleum Operations. The representatives of the Ministry
inspecting and monitoring Petroleum Operations shall comply with the safety
standards of the Contractor.
19
6.8.2
For the purposes of permitting the exercise of the above-mentioned rights, the
Contractor shall provide reasonable assistance to the representatives of the
Ministry, including transportation and accommodation.
6.8.3
All costs directly related to the technical inspection, verification and audit of
Petroleum Operations or otherwise in connection with the exercise of the
Ministry's rights under this Contract or the performance of the Contractor's
obligations shall be borne by the Contractor and are recoverable as Petroleum
Operations Costs in accordance with this Contract, including:
(a)
outbound and return travel expenses;
(b)
local transportation, as necessary;
(c)
accommodation; and
(d)
per diems, which shall be adjusted in accordance with such
amounts assigned to the ranking of each agent of the Ministry as
published in the general budget law of the State approved for
such Calendar Year.
6.9
Provision of Information to Ministry
6.9.1
The Contractor shall keep the Ministry fully informed on the performance and
status of Petroleum Operations at reasonable intervals and as required under
this Contract and of any emergencies or accidents that may have occurred
during such operations. Furthermore, the Contractor shall provide the Ministry
with all documentation and information that is required to be provided under this
Contract and the Hydrocarbons Law and as may otherwise be requested by the
Ministry from time to time.
6.9.2
The Contractor shall keep the Ministry informed on a daily basis of the volumes
of Hydrocarbons produced from the Contract Area.
6.10
Production of Energy for Own Use
The Contractor shall not produce any energy for its own use unless national
production is insufficient or not reliable enough for the demands of the
Contractor in its conduct of Petroleum Operations. In such event, the energy
produced may not be sold to any Person. However, the Contractor may utilize
the amounts of Crude Oil and/or Natural Gas necessary for the production of
power for use in its offshore facilities.
6.11
Standard of Equipment
The Contractor shall ensure that all equipment, plants, installations and
materials used by it comply with the Hydrocarbons Law and generally accepted
engineering standards, and that they are duly constructed and maintained in
good condition.
6.12
Care of Contractor and the Environment
6.12.1
The Contractor shall take all prudent and necessary steps in accordance
with generally accepted practice of the international petroleum industry, the
Hydrocarbons Law and this Contract to:
20
(a)
prevent pollution and protect the environment and living
resources;
(b)
ensure that any Hydrocarbons discovered or produced in the
Contract Area are handled in a manner that is safe for the
environment;
(c)
avoid causing damage to overlying, adjacent and/or underlying
formations trapping Hydrocarbon reserves;
(d)
prevent the ingress of water via Wells into strata containing
Hydrocarbon reservoirs;
(e)
avoid causing damage to overlying, adjacent and/or underlying
aquifers;
(f)
ensure that Petroleum Operations are carried out in accordance
with this Contract, the Hydrocarbons Law and all other laws of
Equatorial Guinea;
(g)
undertake the precautions necessary for the protection of
maritime transportation and the fishing industry and to avoid
contamination of the ocean and rivers;
(h)
drill and exploit each Field in such a manner that the interests of
Equatorial Guinea are protected; and
(i)
ensure prompt, fair and full compensation for injury to Persons or
property caused by the effects of Petroleum Operations.
6.12.2
If the Contractor's actions result in any pollution or damage to the
environment, any Person, living resources, property or otherwise, the
Contractor shall immediately take all prudent and necessary measures to
remedy such damages and effects thereof and/or any additional measures as
may be directed by the Ministry. If the pollution or damage is caused as a result
of the negligence or willful misconduct of the Contractor, its subcontractors or
any Persons acting on its or their behalf all costs in relation thereof shall not be
recoverable as a Petroleum Operations Cost. If the Contractor does not act
promptly so as to control or clean-up any pollution or make good any damage
caused, the Ministry may, after giving the Contractor reasonable notice in the
circumstances, carry out the actions which are prudent or necessary hereunder
and under Article 4.5 and all reasonable costs and expenses of such actions
shall be borne by the Contractor and shall not be recoverable as a Petroleum
Operations Cost.
6.12.3
If the Ministry determines that any works or installations built by the
Contractor or any activity undertaken by the Contractor threatens the safety of
any Persons or property or causes pollution or harm to the environment, the
Ministry shall promptly advise the Contractor of its determination, and may
require the Contractor to take all appropriate mitigating measures, consistent
with generally accepted practice of the international petroleum industry, to
repair any damage caused by the Contractor's conduct or activities.
Furthermore, if the Ministry deems it necessary, it may demand that the
Contractor suspend totally or partially the affected Petroleum Operations until
the Contractor has taken the appropriate mitigating measures or repaired any
damage.
21
6.12.4
The Contractor shall undertake comprehensive environmental impact
assessment studies prior to, during and after major drilling operations. The
Contractor shall assume the costs of these studies and such costs shall be
recoverable. This requirement is mandatory and the first study shall be
presented to the Ministry before the start of the drilling of the first Well in the
Contract Area. However, an environmental impact assessment must also be
completed prior to undertaking any seismic work in any areas of particular
environmental sensitivity specified by the State.
6.13
Re-injection and Flaring of Natural Gas
The Natural Gas that the Contractor does not develop in accordance with this
Contract and the Hydrocarbons Law or use in its own operations within the
Contract Area shall be re-injected into the structure of the subsoil, and all costs
of such re-injection shall be recoverable as a Petroleum Operations Cost.
Notwithstanding the foregoing, the Ministry may authorize the combustion of
Natural Gas for short periods of time in accordance with the Hydrocarbons Law.
All such Natural Gas not used in Petroleum Operations by the Contractor or not
developed in accordance with this Contract and the Hydrocarbons Law shall
remain the sole property of the State.
6.14
Design and Identification of Wells
6.14.1
The Contractor shall conform to the practices generally accepted in the
international petroleum industry in the design and drilling of Wells, including
their casing and cementation.
6.14.2
Each Well shall be identified by a name or number agreed with the
Ministry, which shall be indicated on all maps, plans and other similar records
produced by or on behalf of the Contractor.
6.15
Vertical Projection Wells
No Well may be drilled to an objective which is outside the vertical projection of
the boundaries of the Contract Area. Controlled direction Wells drilled within the
Contract Area from adjacent terrain not covered by this Contract will be
considered for all purposes of this Contract as Wells drilled from territory
included in the Contract Area, and whose drilling may only be undertaken with
the prior approval of the Ministry, and on such terms and conditions as the
Ministry may establish. Nothing in this Article has the intention or should be
interpreted as a grant of a right of lease, license, servitude or any other right
that the Contractor must obtain from the Ministry or other Persons.
6.16
Notification of Commencement of Drilling
The Contractor shall notify the Ministry at least ten (10) Business Days in
advance of the commencement of any drilling of any Well set out in an
approved Annual Work Program and corresponding Annual Budget or before
the resumption of works on any Well whose works have been suspended for
more than six (6) months.
22
6.17
Construction of Facilities
The Contractor shall build and maintain all facilities necessary for the proper
performance of this Contract and the conduct of Petroleum Operations. In order
to occupy land necessary for the exercise of its rights and obligations under this
Contract, the Contractor shall request the authorization of the Ministry and/or
other applicable governmental authorities, which authorization shall be subject
to and granted in accordance with Article 6.19, the Hydrocarbons Law and other
applicable laws of Equatorial Guinea. The Contractor shall repair any and all
damage caused by such circumstances.
6.18
Occupation of Land
6.18.1
In order to carry out Petroleum Operations, the Contractor shall have the
right to:
6.18.2
(a)
subject to Articles 6.17 and 6.18.2, occupy the necessary land for
the performance of Petroleum Operations and associated
activities as set out in paragraphs (b) and (c) below, including
lodging for personnel;
(b)
undertake or procure the undertaking of any infrastructure work
necessary in normal technical and economic conditions for the
carrying out of Petroleum Operations and associated activities
such as transport, storage of equipment, materials and extracted
substances, establishment of telecommunications equipment and
communication lines necessary for the conduct of Petroleum
Operations at installations located both offshore and onshore;
(c)
undertake or ensure the undertaking of works necessary for the
supply of water to personnel and installation works in accordance
with water supply regulations; and
(d)
extract and use or ensure the extraction and utilization of
resources (other than Hydrocarbons) from the subsoil necessary
for the activities stipulated in paragraphs (a), (b) and (c) above in
accordance with relevant regulations.
Occupation of land as mentioned in Article 6.18.1 shall become effective
after the Ministry or other applicable governmental authority approves the
request submitted by the Contractor indicating and detailing the location of such
land and how the Contractor plans to use it, taking the following into
consideration:
(a)
if the land belongs to the State, the State shall grant it to the
Contractor for occupation and to build its fixed or temporary
facilities during the term of this Contract for a fee and on terms to
be agreed and such amount shall be considered a Petroleum
Operations Cost;
(b)
if the land is private property by traditional or local right according
to the Property Registry, then (i) if the occupation is merely
temporary or transitory, or for right of way, the Contractor shall
reach an agreement with the relevant property owner and the
property owner shall reach an agreement with any occupant,
23
tenant or possessor, with regard to the rental to be paid, and the
resulting amounts shall be considered recoverable Petroleum
Operations Costs, or (ii) if the occupation is permanent, the
relevant owner and the Contractor shall reach an agreement
regarding matters related to the property's acquisition and such
amounts shall be considered Petroleum Operations Costs;
6.19
(c)
if the Contractor and the relevant property owner or occupant,
tenant or possessor do not reach an agreement regarding the
matters mentioned in paragraph (b) above, the Ministry shall act
as a mediator between them and in the event that such
mediation does not produce a resolution of the case the dispute
shall be resolved by the courts of Equatorial Guinea unless
recourse is had to the procedure described in paragraph (d)
below;
(d)
the State may proceed to expropriate the land, subject to the
prior publication of a decree of compulsory expropriation followed
by a fair and reasonable valuation of the land concerned by an
expert valuator. In such event the Contractor shall compensate
the expropriated property owner in accordance with the value
determined by such expert valuator if the State has not done so;
such amounts shall be considered recoverable Petroleum
Operations Costs;
(e)
the relinquishment, in whole or in part, of the Contract Area, will
not affect the Contractor’s rights under Article 6.18.1 to carry out
building works and construction of installations, provided that
such works and installations are directly related to other activities
of the Contractor in the remainder of the Contract Area, as in the
case of partial relinquishment, and covered by other production
sharing contracts.
Residence of Personnel
There shall be no restrictions imposed on the entry, residence, free circulation,
employment and repatriation of the personnel of the Contractor and its
subcontractors, the family of such personnel, or the personal effects of such
personnel and his or her family, provided that the Contractor and its
subcontractors comply with all applicable laws including employment and social
legislation of Equatorial Guinea. The State agrees to grant in a timely manner
the entry, work, or residence permits or other permits or authorizations that, in
accordance with the Laws of Equatorial Guinea, may be required by the
personnel of the Contractor, the Technical Operator or any subcontractor.
6.20
Assistance of Ministry
The Ministry shall assist the Contractor and its subcontractors in obtaining all
administrative authorizations and licenses as may be reasonably necessary for
the proper execution of Petroleum Operations under this Contract.
6.21
Opening of Branch Office
The Contractor shall, to the extent that it has not already done so, open a
representative branch office in Equatorial Guinea within six (6) months following
24
the Effective Date, which shall exist and be maintained during the term of this
Contract. Such branch office shall always be staffed by at least one (1)
representative with sufficient authority to make decisions on behalf of the
Contractor.
6.22
Premises
Upon the first Commercial Discovery, the Contractor shall, to the extent that it
has not already done so, construct a prestigious building for its offices in
Equatorial Guinea using modern and permanent materials and of an
appropriate size and design as shall be approved by the Ministry. All costs
related to such construction shall be recoverable as Petroleum Operation Costs
in accordance with this Contract. Once such construction costs have been
recovered by the Contractor, such property shall be owned solely by the State
and the Contractor shall pay rent to the State at a price and on terms to be
negotiated and such rent shall be considered recoverable Petroleum Operations
Costs.
ARTICLE 7 - ROYALTIES, RECOVERY OF PETROLEUM OPERATIONS COSTS,
AND DISTRIBUTION OF PRODUCTION
7.1
Royalties
7.1.1
The Contractor shall pay Royalties to the State from the first day of Production
based on the daily Total Disposable Production from a Development and
Production Area. The calculation shall be determined according to the following
table applicable for each tranche:
Daily Total Disposable
Production
(Barrels per day)
Royalt
y
(%)
From 0 to ●
13
●
●
●
●
●
●
7.1.2
The percentage corresponding to the level of Production shall be applied
directly. Thus, for example: for a Production level of [insert number] ([insert
number]) Barrels per day, [insert percentage] percent ([insert percentage]%)
would be payable and the Royalty would be [insert number] ([insert number])
Barrels.
7.2
Cost Recovery Oil
7.2.1
After deducting Royalties, the Contractor shall be entitled to up to [insert
number] percent ([insert number]%) of the Total Disposable Production
remaining in any Calendar Year for recovery of its Petroleum Operations Costs
(Cost Recovery Oil).
25
7.2.2
The value of the portion of Total Disposable Production assigned to the
Contractor’s Petroleum Operations Costs recovered will be determined in
accordance with Article 10.
7.2.3
If, during any Calendar Year, the Petroleum Operations Costs not yet recovered
by the Contractor in accordance with this Contract exceed the value of the
maximum amount of available Cost Recovery Oil, the portion of Petroleum
Operations Costs not recovered in the said Year will be carried forward to the
following Calendar Year for recovery purposes.
7.3
Net Crude Oil
The quantity of Total Disposable Production remaining every Year after the
deduction of Royalties and Cost Recovery Oil will hereafter be referred to as
Net Crude Oil, which will be shared between the State and the Contractor in
the following proportions:
Accumulated Total
Production
(Million Barrels)
Entitlement of the State (%) Entitlement of the
Contractor
●
●
●
●
●
7.4
7.5
7.5.1
7.5.2
(%)
●
●
●
●
●
Delivery of State's Entitlement
●
The State’s share of Crude Oil to which it is entitled pursuant to ●Articles 7.1 and
● appointed by
7.3 shall be delivered to and accepted by the State or the Person
●
it at the Delivery Point. The Contractor shall be free from all responsibility
with
●
respect to such Crude Oil from the time it has been delivered. However, should
the State so require, the Contractor shall be obliged to purchase all or part of
the State’s share of Total Disposable Production, subject to the
● provisions of
Article 7.5.
●
●
●
Price Obtained by Contractor
●
If, pursuant to Article 7.4, the State requires the Contractor to purchase its
share of Crude Oil, the State shall advise the Contractor of its next scheduled
●
shipment at least three (3) months in advance, and the Ministry
and the
Contractor shall come to a mutual agreement as to the terms and conditions
of
●
such sale and purchase. In the event that three (3) months advance notice is
●
not given, or they do not reach an agreement as to the terms and conditions
of
the sale and purchase, the Contractor shall not be obliged to purchase
said
●
Crude Oil.
The Ministry shall be entitled to compare the price for its Crude Oil obtained
from the Contractor with similar market quotations. In the event that it is shown
that the price obtained from the Contractor differs substantially from the
quotations in similar markets, the Ministry shall have the right to evaluate the
Contractor’s sales and marketing operations and, if justified, cancel any sales
26
agreement between the State and the Contractor, without prejudice to any claim
that the State may have against the Contractor with respect to the matters
under dispute.
7.6
Export of Entitlement
Subject to Article 12 and the Hydrocarbons Law, each Party comprising the
Contractor has the right to take, receive and freely export its share of Net Crude
Oil and Cost Recovery Oil, provided it uses the services of an Equatoguinean
Crude Oil maritime transport company, an international company associated
with the National Company or any other local business that is able to provide
the services under conditions that are internationally competitive in terms of
price, quality, terms of payment and availability in accordance with Article 23.1.
7.7
Title to Contractor's Entitlement
Title to the Contractor’s portion of Net Crude Oil and Cost Recovery Oil shall
pass to the Contractor at the Delivery Point.
ARTICLE 8 - PARTICIPATION INTERESTS
8.1
Liability for Petroleum Operations Costs
Subject to Article 8.2, the Parties comprising the Contractor shall fund, bear and
pay all costs and expenses for Petroleum Operations under this Contract and
the Joint Operating Agreement in the proportions set forth in Article 1.3. Each of
the Parties comprising the Contractor shall be represented on the operating
committee under the JOA and shall have voting rights as provided therein.
8.2
Participation Interest of the National Company
8.2.1
The National Company’s Participation Interest will be carried and paid for in full
by the other Parties comprising the Contractor (other than the National
Company) in proportion to their respective Participation Interests (other than the
National Company's) until such time as the National Company elects to convert
its carried Participation Interest into a full working Participation Interest in
accordance with the Hydrocarbons Law. From that point on, the National
Company shall be responsible for all its costs in respect of the area covered by
the approved Development and Production Plan. For the avoidance of doubt,
the National Company's Participation Interest in respect of the remainder of the
Contract Area shall continue to be carried and paid for by the Parties
comprising the Contractor (other than the National Company) in proportion to
their respective Participation Interests (not including the National Company's)
until such time as the National Company elects to convert its carried interest
into a full working interest.
8.2.2
The costs, expenditures and obligations incurred by the Parties comprising the
Contractor (other than the National Company) in relation to the National
Company’s carried Participation Interest shall be recoverable by the Parties
27
comprising the Contractor (other than the National Company) in accordance
with the provisions of this Contract and the Hydrocarbons Law.
8.2.3
The Parties comprising the Contractor (other than the National Company) shall
recover the costs and expenditures in relation to the National Company’s
carried Participation Interest from fifty percent (50%) of the Hydrocarbons
corresponding to the National Company’s total entitlement.
ARTICLE 9 - TAXATION
9.1
Payment of Taxes
Except as otherwise provided in this Contract, the Contractor, its subcontractors
and their respective employees, agents, consultants and other personnel shall
be subject to the Tax Law and all regulations passed pursuant thereto, as well
as UDEAC (Central African Economic and Monetary Union) and fiscal and
customs laws of Equatorial Guinea.
9.2
Audit Rights
The provisions of Article 16 shall apply to Income Tax, Royalty payments and to
all other obligations under this Contract.
ARTICLE 10 - VALUATION OF CRUDE OIL
10.1
Calculation of Market Price
10.1.1
The unit selling price of Crude Oil under this Contract shall be the FOB
Market Price at the Delivery Point, expressed in Dollars per Barrel and
calculated in accordance with this Article 10.1. A Market Price shall be
established for each type of Crude Oil or Crude Oil blend.
10.1.2
The Market Price applicable to all liftings of Crude Oil during a Quarter
shall be calculated at the end of that Quarter and shall be equal to the weighted
average of prices obtained by the Parties comprising the Contractor for Crude
Oil sold to or purchased from third parties on an arm’s length basis during that
Quarter, further adjusted as necessary to reflect differentials in quality, gravity,
quantity, delivery conditions and terms of payment; provided that, the quantities
sold to or purchased from third parties during that Quarter constitute at least
fifteen percent (15%) of the total quantities of Crude Oil won and saved from all
the Fields under this Contract and sold or purchased during such Quarter.
10.1.3
In the event that such sales to or purchases from third parties are not
made during the Quarter in question or represent less than fifteen percent
(15%) of the total quantities of Crude Oil won and saved from all the Fields
under this Contract and sold or purchased by the Contractor during said
Quarter, the Market Price shall be equal to the weighted average of:
(a)
the average of the International Petroleum Exchange (IPE)
Dated Brent quotations as published in Platts; and
(b)
the average of the quotations as published in Platts for one (1) or
several types of Crude Oil of similar quality to that produced in
28
West Africa and to be mutually agreed between the Ministry and
the Contractor for the Quarter in question, adjusted as necessary
to reflect differentials in quality, gravity, quantity and terms and
conditions of delivery and payment.
10.1.4
10.1.5
The following transactions shall be excluded from the calculation of the
Market Price:
(a)
sales in which the buyer is an Affiliated Company of the seller
(unless such sales are on an arm’s length basis) as well as sales
between the Persons comprising the Contractor;
(b)
sales between the providers of Crude Oil and the local market;
and
(c)
sales for consideration other than payment in a freely convertible
currency and sales wholly or partially made for reasons other
than the usual economic incentives involved in Crude Oil sales
on the international market (such as exchange contracts).
The Market Price of Crude Oil shall be established:
(a)
taking into consideration the evolution of the international
market; and
(b)
if the Crude Oil used to calculate the Market Price ceases to be
quoted, the Ministry and the Contractor shall agree on the Crude
Oil which most closely approximates to the Crude Oil the
quotation of which has ceased for the purposes of calculating the
Market Price.
10.2
Disagreement of Market Price
10.2.1
The Contractor and the Ministry shall agree the Market Price in
accordance with this Article 10; in the event that they are unable to agree on
any matter concerning the Market Price of Crude Oil, either the Contractor or
the Ministry may serve on the other a dispute notice. Within seven (7) days of
the date of the dispute notice the Ministry shall establish a committee of two (2)
Persons of which the Minister of Mines, Industry and Energy or his delegate will
be the President and the other committee member will be a representative
designated by the Contractor to represent it. The committee must meet and
make a decision resolving any dispute under this Article 10 within thirty (30)
days of the date of the dispute notice. The committee shall unanimously decide
the dispute.
10.2.2
In the event a unanimous decision is not reached by the committee
within the aforementioned thirty (30) day period, the dispute shall be determined
by an internationally recognized expert appointed by the International Chamber
of Commerce in accordance with its Rules for Expertise (ICC Expertise Rules).
The determination of the expert shall be final and binding on the Parties. The
expert shall determine the Market Price in accordance with the provisions of this
Article 10 within twenty (20) days from the date of his appointment. Unless
otherwise determined by the expert, the costs and expenses of such expert
shall be shared proportionately by the Parties on a per capita basis and the
Contractor’s share shall not be cost recoverable.
29
10.2.3
Pending the determination of the Market Price for a Quarter, the Market
Price provisionally applicable to a Quarter shall be the Market Price of the
preceding Quarter. Any necessary adjustment shall be made no later than thirty
(30) days after the determination of the Market Price for the Quarter in question.
10.3
Payment of Market Price
Within ten (10) days after each shipment, the Contractor shall provide the
Ministry with full details of the prices achieved for the sale of each shipment of
the State's Crude Oil and will remit all funds to the State within fourteen (14)
days after receipt thereof by the Contractor.
10.4
Audit of Market Price
The Ministry shall be entitled to audit and verify that the price obtained by the
Contractor for each shipment of Crude Oil has been the price determined in
accordance with this Contract. The Ministry has the right, during a period of two
(2) Years from the transaction date, to assess the marketing practices of the
Contractor and require the Contractor to pay the State for the difference
between the price actually obtained and the Market Price determined in
accordance with this Article 10.
ARTICLE 11 - BONUSES AND SURFACE RENTALS
11.1
Signature Bonus
The Contractor shall pay to the State a signature bonus of [insert amount]
Dollars ($[insert amount]) within thirty (30) days of the Effective Date.
11.2
Discovery Bonus
On the date the Contractor notifies the Ministry for the first time that it deems a
Discovery to be a Commercial Discovery in compliance with the provisions of
Article 5.4, the Contractor shall pay to the State the sum of [insert amount]
Dollars ($[insert amount]).
11.3
Production Bonuses
The Contractor shall pay to the State the following sums as Production
bonuses:
(a)
on the date of start Production of Crude Oil from a Development
and Production Area, [insert amount] Dollars ($[insert
amount]);
(b)
[insert amount] Dollars ($[insert amount]) after daily
Production from a Development and Production Area first
averages [insert number] Barrels per day for a period of sixty
(60) consecutive days;
(c)
[insert amount] Dollars ($[insert amount]) after daily Production
from a Development and Production Area first averages [insert
30
number] Barrels per day for a period of sixty (60) consecutive
days;
(d)
[insert amount] Dollars ($[insert amount]) after daily
Production from a Development and Production Area first
averages [insert number] Barrels per day for a period of sixty
(60) consecutive days; and
(e)
[insert amount] Dollars ($[insert amount]) after daily
Production from a Development and Production Area first
averages [insert number] Barrels per day for a period of sixty
(60) consecutive days.
Such payments shall be made within thirty (30) days of the date that the liability
accrues.
11.4
Surface Rentals
11.4.1
The Contractor shall pay to the State the following annual surface
rentals:
11.4.2
(a)
[insert amount] Dollars ($[insert amount]) per hectare of the
Contract Area annually, for each Calendar Year or part thereof,
during the Initial Exploration Period, the Extension Periods or
any extension thereof; or
(b)
[insert amount] Dollars ($[insert amount]) per hectare for each
Development and Production Area, annually for each Calendar
Year or part thereof, during the term of the relevant Development
and Production period.
For the Year in which this Contract is signed, the surface rental set forth
in Article 11.4.1(a) shall be prorated from the Effective Date through to 31
December of such Year and shall be paid within thirty (30) days after the
Effective Date. For succeeding Years the surface rentals set forth in Article
11.4.1(a) and (b) shall be paid in advance not less than thirty (30) days before
the beginning of each Calendar Year.
For the Calendar Year in which any Development and Production Area is
granted the surface rental set forth in Article 11.4.1(a) and (b) shall be prorated
from the date in which such Development and Production Plan is approved up
to 31 December of said Calendar Year, and the additional sum shall be paid
within thirty (30) days after the approval of the Development and Production
Area. For succeeding Calendar Years the surface rental set forth in Article
11.4.1(b) shall be paid within thirty (30) calendar days after the beginning of
each Calendar Year.
11.4.3
Surface rentals shall be calculated based on the surface of the Contract
Area and, where applicable, of a Development and Production Area occupied
by the Contractor on the date of payment of such surface rentals. For the
avoidance of doubt, this shall exclude any relinquished areas. In the event of
relinquishments made during a Calendar Year, the Contractor shall have no
right to be reimbursed for the surface rentals already paid.
31
ARTICLE 12 - OBLIGATION TO SUPPLY DOMESTIC MARKET
12.1
Obligation to Supply
In accordance with the Hydrocarbons Law, the Contractor shall meet as a
priority the needs of domestic Hydrocarbon consumption in Equatorial Guinea.
For this purpose, and in accordance with the provisions of Articles 86 and 87 of
the Hydrocarbons Law, if the State so requests, the Parties comprising the
Contractor (other than the National Company) shall sell to the State at the
Delivery Point a portion of its Net Crude Oil and/or Net Natural Gas for internal
consumption in the country.
12.2
Notification from Ministry
No later than the first day of October of each Calendar Year, the Ministry shall
notify the Parties comprising the Contractor (other than the National Company)
of the quantities of Crude Oil and/or Natural Gas which it desires to purchase
under this Article 12 for the subsequent Calendar Year. The Crude Oil and/or
Natural Gas shall be delivered to the State or to the beneficiary designated by
the State during such Calendar Year according to procedures to be agreed
between the Ministry and the Contractor.
ARTICLE 13 - NATURAL GAS
13.1
Unassociated Natural Gas
13.1.1
In the event of an Unassociated Natural Gas Discovery, the Contractor
shall comply with the provisions of Article 5.2. However, if the Appraisal work
program presented by the Contractor following the Discovery of Unassociated
Natural Gas has a duration exceeding that of the Initial Exploration Period or
any of its extensions, the Contractor may request from the Ministry an extension
of the relevant Exploration Period with respect to the Appraisal Area related to
such Discovery for a period of up to four (4) Years starting from the expiry of the
Initial Exploration Period or any of its Extension Periods, as appropriate. The
Contractor shall request the aforementioned extension at least sixty (60) days
prior to the expiry of the relevant period.
13.1.2
If the Contractor considers that the Unassociated Natural Gas Discovery
does not warrant Appraisal or further Appraisal, in conformity with the
provisions of Article 5.12, the Ministry may, with ninety (90) days' advance
notice, require the Contractor to relinquish all of its rights over the Appraisal
Area encompassing such Discovery.
13.1.3
In the same manner, if after completion of the Appraisal work, the
Contractor considers that the Unassociated Natural Gas Discovery is not
commercial, the Ministry may, with ninety (90) days' advance notice, require the
Contractor to relinquish all of its rights over the Appraisal Area encompassing
such Discovery.
32
13.1.4
In both the above cases the Contractor shall be deemed to have waived
all its rights to the Hydrocarbons produced from such Unassociated Natural Gas
Discovery, and the State may then carry out, or cause to be carried out, all the
Petroleum Operations relating to that Discovery, without compensation or
indemnification to the Contractor, provided, however, that such work shall not
prejudice the performance of other Petroleum Operations of the Contractor. The
Ministry may request that the Contractor undertake all continuing operations for
a fee and on terms to be agreed between the Ministry and the Contractor.
13.2
Associated Natural Gas
13.2.1
In the event that a Discovery of Crude Oil is considered to be a
Commercial Discovery, the Contractor shall state in the report referred to in
Article 5.3 whether it considers that the Production of Associated Natural Gas is
likely to exceed the quantities necessary for the requirements of Petroleum
Operations relating to the Production of Crude Oil (including re-injection
operations), and whether it considers that such excess is capable of being
produced in commercial quantities. In the event the Contractor has informed the
Ministry of such an excess, the Ministry and the Contractor shall jointly assess
the possible markets and uses for such excess of Associated Natural Gas, both
on the local market and for export (including the possibility of joint marketing of
their shares of Production of that excess of Associated Natural Gas in the event
such excess would not otherwise be commercially exploitable), together with
the means necessary for its marketing.
13.2.2
In the event the Ministry and the Contractor should decide that the
Development of the excess Associated Natural Gas is justified, or in the event
the Contractor should wish to develop and produce such excess, the Contractor
shall indicate in the Development and Production Plan the additional facilities
necessary for the Development and Production of such excess and its estimate
of the costs related thereto. The Contractor shall then proceed with the
Development and Production of such excess in accordance with the
Development and Production Plan submitted and approved by the Ministry
under Article 5.5. A similar procedure shall be applicable if the sale or marketing
of Associated Natural Gas is agreed during the Production of a Field.
13.2.3
In the event the Contractor does not consider the exploitation of the
excess Associated Natural Gas is justified and if the State at any time wishes to
utilize it, the Ministry shall notify the Contractor of the State's wish, in which
event:
(a)
the Contractor shall put at the disposal of the State free of
charge the Crude Oil and Associated Natural Gas separation
facilities for all or part of such excess that the State wishes to
utilize;
(b)
the State shall be responsible for the gathering, treatment,
compression and transportation of such excess Associated
Natural Gas from the receiving point at the Contractor’s facilities
and for bearing any additional costs and liabilities related thereto;
and
(c)
the construction of the facilities necessary for the operations
referred to in paragraph (b) above, together with the recovery of
that excess by the State, shall be carried out in accordance with
33
generally accepted practice of the international petroleum
industry.
13.2.4
In no event shall the Operations carried out by the State in relation to
such Associated Natural Gas interfere with Petroleum Operations of the
Contractor.
13.2.5
Any excess Associated Natural Gas not utilized in accordance with
Articles 13.2.1, 13.2.2 and 13.2.3 shall be re-injected by the Contractor in
accordance with Article 6.14. Flaring will be permitted only in accordance with
the Hydrocarbons Law and is subject to the approval of the Ministry. The
Contractor shall be permitted to flare Associated Natural Gas without the
approval of the Ministry in the event of an emergency, provided that every effort
is made to diminish and extinguish such flaring of Natural Gas as soon as
possible. The Ministry has the right to offtake, free of charge, at the wellhead or
gas oil separator all Natural Gas that would otherwise be re-injected or flared by
the Contractor.
13.3
Provisions Common to Associated and Unassociated Natural Gas
13.3.1
The Contractor shall dispose of its share of the Production of Natural
Gas in accordance with this Contract and the Hydrocarbons Law. The
provisions of this Contract applicable to Crude Oil shall apply mutatis mutandis
to Natural Gas unless otherwise specified herein.
13.3.2
The selling price for all Natural Gas to be sold in the domestic market
shall be set by the Ministry in accordance with the Hydrocarbons Law. The
selling price for all Natural Gas to be sold outside of the domestic market shall
be as agreed between the Ministry and the Contractor. The Ministry and
Contractor shall proceed in good faith to negotiate a gas sales agreement, if
required.
13.3.3
For the purposes of Articles 7.3 and 11.3, the quantities of available
Natural Gas after deduction of the quantities re-injected, flared or necessary for
the conduct of Petroleum Operations shall be expressed in a number of Barrels
of Crude Oil on a BTU equivalent energy content basis adjusted monthly by a
commercially appropriate factor relating the price of Natural Gas with the price
of Crude Oil in terms of the provisions of Article 10.3, unless otherwise agreed
between the Ministry and the Contractor.
13.3.4
The provisions of Article 7.2 in respect of cost recovery shall apply
mutatis mutandis to the Production of Natural Gas.
13.3.5
The quantity of Natural Gas produced and saved from the Contract Area
which remains after the Contractor has taken the portion for the recovery of
Petroleum Operations Costs pursuant to Article 13.3.4 shall be referred to as
Net Natural Gas.
13.3.6
Subject to the Hydrocarbons Law, the Ministry and the Contractor
hereby agree that, in the case of Natural Gas Production, they shall reach
separate agreements and arrangements with respect to the sale and marketing
of Natural Gas.
34
ARTICLE 14 - CUSTOMS REGULATIONS
14.1
Importation of Goods, etcetera
14.1.1
In accordance with the stipulations of Articles 63 and 64 of the
Hydrocarbons Law, the Contractor shall be permitted to import into Equatorial
Guinea all the goods, materials, machinery, equipment and consumer goods
directly necessary to properly carry out Petroleum Operations in its own name
or in the name of its sub-contractors or other Persons acting on its or their
behalf.
14.1.2
For the purpose of this Contract, the Contractor shall benefit from the
following advantages:
(a)
under the conditions stipulated in the Customs Code, the
importation in compliance with the regulations of Temporary
Admission (TA) or Temporary Imports (TI), either normal or
special, whichever is the case for the Contractor, for its subcontractors and Persons acting on its or their behalf, of all
materials, products, machinery, equipment and tools necessary
for Petroleum Operations, on condition that these goods are
exclusively destined and effectively devoted to Petroleum
Operations and destined to be re-exported at the end of their
use;
(b)
admission with exemption from any tax and/or duty of all
materials, products, machinery, equipment and tools destined
exclusively and effectively devoted to Hydrocarbon prospecting,
Exploration and Production in the specified area and listed in
Annex 2 of Act Number 13/65-UDEAC-35 dated 14 December
1965;
This exemption applies to imports directly made by the
Contractor, its sub-contractors and Persons acting on its or their
behalf, on condition that a certificate of end use is issued.
(c)
under the same aforementioned conditions, the Contractor is
entitled to import at a reduced duty rate of five percent (5%)
materials, products, machinery, tools and equipment which do
not fall under the category of any goods specified under
paragraphs (a) and (b) above but are necessary and required for
the Production, storage, treatment, transport and shipment of
Hydrocarbons from the Contract Area.
The reduced duty rate will be granted by the Ministry of Finance
and Budget at the request of the Contractor:
(i)
on submission of a general import schedule; or
(ii)
after submitting a particular application for a reduced
rate
import; the Contractor shall submit such
application at least fifteen (15) days before the arrival of
the goods in Equatorial Guinea.
35
These applications should specify:
(d)
(i)
the commercial nature of the goods and the customs
consignment in which they are classified; and
(ii)
the value of the goods in FOB and CIF;
goods and household items for personal and domestic use that
the Contractor’s foreign personnel devoted to Petroleum
Operations imports upon their relocation will be admitted dutyfree according to the conditions established in the Customs
Code and in particular Articles 17 to 20 of Act 13/75-UDEAC-35
dated 14 December 1975, as amended.
14.1.3
All goods, material, products, machinery, tools and equipment not
mentioned under Article 14.1.2 are subject to taxes and/or import duties, as
provided by the Customs Authorities in Equatorial Guinea.
14.2
Export of Entitlement and Goods etc.
14.2.1
Subject to Article 12, the Contractor, its purchasers and transporters will
have the right to export freely and at any time the quantities of Cost Recovery
Oil and Net Crude Oil belonging to the Contractor from the Delivery Point
selected for this purpose free of taxes and/or duties.
14.2.2
In compliance with the customs obligations as set out in this Contract
and regulations currently in force, the Contractor, its sub-contractors and
Persons acting on its or their behalf may re-export, free of taxes and/or import
duties, goods imported within the framework of this Contract when they are no
longer necessary for Petroleum Operations, provided that their ownership has
not been transferred to the State in accordance with the terms of this Contract.
14.3
Customs Authorities
All imports, exports and re-exports carried out under this Contract shall be
subject to the formalities required by the Customs Authorities.
14.4
Joint and Several Liability
The Contractor is jointly and severally liable with its subcontractors and any
Persons acting on its or their behalf for any infraction in the use and enjoyment
by them of the advantages set out in this Article 14. Fines, penalties and
payments of any nature incurred by any guilty party shall not constitute a
Petroleum Operations Cost.
14.5
Other Taxes, etcetera
Other than taxes and/or import duties as provided for in this Article 14, the
Contractor, its sub-contractors and Persons importing on its or their behalf will
not be subject to any other payment in this respect.
36
14.6
Foreign Personnel
Foreign personnel assigned to work in Equatorial Guinea on behalf of the
Contractor or its sub-contractors, and their families, shall be permitted to import
their personnel effects into Equatorial Guinea free of customs duties.
ARTICLE 15 - FOREIGN CURRENCY
15.1
Exchange Control Laws
The Contractor and its subcontractors and all Persons acting on its or their
behalf must comply with all applicable exchange control laws of Equatorial
Guinea. However, as long as they shall have met their respective payment and
tax obligations under this Contract and the laws of Equatorial Guinea, they shall
benefit, during the term of this Contract, from the following rights regarding
Petroleum Operations:
(a)
to retain or dispose of any proceeds outside of Equatorial Guinea
including any proceeds from the sale of its or their share of
Hydrocarbons;
(b)
to pay foreign subcontractors and expatriate employees of the
Contractor, outside of Equatorial Guinea, after deduction of the
relevant taxes in Equatorial Guinea. For this purpose, the
Contractor may open and use freely bank accounts in Dollars or
in other currencies in banks of its choice in Equatorial Guinea
and abroad. Notwithstanding the foregoing, while this Contract is
in force the Contractor and each of its subcontractors shall
establish and maintain a bank account in a national banking
institution in Equatorial Guinea, which shall have a minimum
balance of, in the case of the Contractor, an amount equivalent
to ten percent (10%) of the current Annual Budget which has
been approved by the Ministry and, in the case of
subcontractors, the minimum amount set by the Ministry from
time to time;
(c)
to transfer such funds as the Contractor or its subcontractors
shall have imported into Equatorial Guinea, or earned from
Petroleum Operations, or from the proceeds of the sale or lease
of goods or performance of services under this Contract;
(d)
to obtain abroad loans required for the performance of their
activities under this Contract, provided that the Ministry shall
have approved the terms of such loan, including the rate of
interest and terms of repayment;
(e)
to collect and maintain abroad all the funds acquired or borrowed
abroad, and to freely dispose thereof, limited to the amounts that
exceed the requirement of funds for their operations in Equatorial
Guinea; and
(f)
free movement of funds owned by them according to the laws of
Equatorial Guinea.
37
15.2
Report on Foreign Exchange Transactions
The Contractor and its subcontractors shall submit to the Ministry of Finance
and Budgets, within forty-five (45) days of the end of each Quarter, a report with
details of any foreign exchange transactions made during the preceding
Quarter, including any transactions directly related to Petroleum Operations on
accounts opened abroad and made in accordance with the provisions of Article
15.1.
15.3
Freedom of Exchange
The Contractor’s and its subcontractors’ expatriate employees shall be
permitted, in accordance with the regulations then in effect in Equatorial
Guinea, to freely exchange and to freely transfer to their country of origin any
savings arising from their salaries, as well as any retirement and personal
benefits paid by or for such employees, provided they have met their tax
obligations in Equatorial Guinea.
ARTICLE 16 - BOOKS, ACCOUNTS, AUDITS AND PAYMENTS
16.1
Maintenance of Records and Books
16.1.1
The Contractor shall at all times maintain at its offices in Equatorial
Guinea the original records and books of Petroleum Operations in accordance
with all applicable regulations and the Accounting Procedure.
16.1.2
All records and books shall be maintained in the Spanish and English
languages and be denominated in Dollars, or such other currency as shall be
requested by the Ministry from time to time. They shall be supported by detailed
documents demonstrating the expenses and receipts of the Contractor under
this Contract. Such records and books shall be used to determine the
Contractor's Gross Revenues, Petroleum Operations Costs and net profits, and
to establish the Contractor’s Income Tax and other payment obligations. Such
records and books shall also include the Contractor’s accounts showing sales
of Hydrocarbons.
16.2
Submission of Accounts
Within ninety (90) days after the end of a Calendar Year, the Contractor shall
submit to the Ministry detailed accounts showing the Petroleum Operations
Costs which the Contractor has incurred during such Calendar Year. The
Contractor may request the approval of the Ministry for an additional extension
of up to thirty (30) days; such approval shall not be unreasonably withheld or
delayed. The accounts shall be certified by an independent external auditor
acceptable to the Ministry and the Contractor. The expenses of such an auditor
shall be met by the Contractor and shall be deemed a Petroleum Operations
Cost.
16.3
Audit of Ministry
16.3.1
After notifying the Contractor, the Ministry may have experts of its
choice or its own agents examine and audit any records and books relating to
Petroleum Operations. The Ministry has a period of three (3) years from the
38
date the Contractor submits to the Ministry such records and books in
accordance with Article 16.2, to perform such examinations or audits with
respect to the said Calendar Year and submit its objections to the Contractor for
any contradictions or errors found during such examinations or audits.
16.3.2
The Contractor shall provide to the Persons designated by the Ministry
any necessary assistance for the foregoing purpose and facilitate the
performance of their duties. The Contractor shall bear all reasonable expenses
incurred in such examination or audit, which shall be recoverable as Petroleum
Operations Costs. However, any expenses incurred for the audit and inspection
of accounting books and records outside of Equatorial Guinea due to the
Contractor’s non-compliance with this Article 16 shall be borne by the
Contractor and will not be recoverable as a Petroleum Operations Cost or
deductible for tax purposes.
16.3.3
In the event of a disagreement between the Ministry and the Contractor
in relation to the results of any examination or audit, the dispute shall be
determined by an internationally recognized expert appointed by the
International Chamber of Commerce in accordance with its Rules for Expertise
(ICC Expertise Rules). The determination of the expert shall be final and
binding on the Parties. Unless otherwise determined by the expert, the costs
and expenses of such expert shall be met proportionately by the Parties on a
per capita basis and the Contractor's share shall not be a Petroleum Operations
Cost.
16.4
Currency and Account of Payments
16.4.1
All payments between the Parties under this Contract shall, unless
otherwise agreed, be in Dollars, or such other currency as shall be requested
by the Ministry from time to time. Subject to Article 16.4.2, when the receiving
Party is the State, payments shall be made to the General Treasury of the
State, and when the receiving Party is the Contractor, payments shall be made
to a bank account designated by the Contractor and notified to the Ministry.
16.4.2
All payments to be made to the Ministry pursuant to Article 23.2.2 shall
be made to such account as shall be notified to the Contractor.
16.5
Timing and Overdue Payments
Unless otherwise agreed, all payments under this Contract shall be made within
thirty (30) days following the date on which the obligation to make such
payment occurs. In the event of a delay in payment the amount due shall bear
interest compounded monthly at the rate of LIBOR plus two percent (2%) per
annum.
ARTICLE 17 - TRANSFER, ASSIGNMENT AND CHANGE OF CONTROL
17.1
Transfer to Equatoguinean Affiliate
Within the one (1) Calendar Year following the Effective Date, to the extent that
they have not already done so, each of the Parties comprising the Contractor
(other than the National Company) shall incorporate an Affiliate under the laws
of Equatorial Guinea and shall assign all of its rights and obligations in and
39
under this Contract, the Joint Operating Agreement and any other agreement
relating to Petroleum Operations to such Affiliate. After such transfer, all of the
rights and obligations of the Parties comprising the Contractor under this
Contract, the Joint Operating Agreement and any other agreements relating to
Petroleum Operations shall be assumed by such Affiliate(s). Any assignment or
transfer under this Article 17.1 shall not be subject to the provisions of Articles
17.2 and 17.3. The foregoing assignment or transfer shall not affect any parent
company or bank guarantee provided pursuant to this Contact.
17.2
Assignment, Transfer, Change of Control
17.2.1
The assignment, transfer, encumbrance or other disposition of the rights
and/or obligations of a Party comprising the Contractor shall require the prior
consent of the Ministry. Any request for authorization shall be accompanied by
all information related to the assignment, transfer, encumbrance or other
disposition including all legal instruments, in final draft form, to be used to carry
out the proposed transaction, the identity of all parties to the transaction, the
estimated value of the transaction and whether the consideration is payable in
kind, securities, cash or otherwise. Such assignment, transfer, encumbrance or
other disposition shall be subject to the payment of a non-recoverable, nondeductible fee and other requirements stipulated in the authorization issued by
the Ministry. The assignee and the assignor shall be jointly and severally liable
for the payment of such fee and for the fulfillment of any other requirements.
17.2.2
All assignees must:
(i)
have the technical and financial ability to meet its obligations
under this Contract;
(ii)
in relation to the interest assigned, accept and assume all of the
terms and conditions of this Contract, the Joint Operating
Agreement and any other agreements relating to Petroleum
Operations; and
(iii)
be an entity with which the Ministry and each of the Parties
comprising the Contractor can legally do business and be
incorporated in Equatorial Guinea.
17.2.3
All profits resulting from any assignment, transfer or other disposition of
any rights and/or obligations under this Contract, regardless of the type and
location of the transaction, shall be subject to taxation in conformity of the Tax
Law of Equatorial Guinea.
17.3
Change of Control
For the purposes of this Article 17, the transfer of ownership of more than fifty
percent (50%) of the shares of any Party comprising the Contractor (other than
the National Company) or any similar transfer that results in a change of Control
shall be deemed to be an assignment of contractual rights under this Contract
and consequently subject to the terms and conditions of this Article 17.
40
17.4
Recourse to Third Party Funding
Recourse by any Party comprising the Contractor to third party funding which
involves the assignment of rights over its entitlement to Hydrocarbons under
this Contract is not permitted without the prior consent of the Ministry.
17.5
The National Company's Right of Preemption
When an assignment, transfer or other disposition of any rights under this
Contract is anticipated, the assigning Party must notify in writing the National
Company as soon as practicable. The National Company shall then have the
right to purchase the assigning Party’s interest under this Contract and
proposed to be assigned, transferred or otherwise disposed of on the same
terms and conditions as those offered to a bona-fide assignee. This right is in
addition to any right of pre-emption granted to the National Company under the
Joint Operating Agreement.
ARTICLE 18 - INDEMNIFICATION, LIABILITY AND INSURANCE
18.1
Liability and Indemnity
18.1.1
The Contractor shall indemnify, hold harmless and compensate any
Person, including the State, for any damage or loss which the Contractor, its
Affiliates, its subcontractors and their respective directors, officers, employees,
agents or consultants and any other Person acting on its or their behalf may
cause to such Person or their property in the conduct of Petroleum Operations.
All costs incurred under this Article 18.1 caused by the negligence or willful
misconduct of the Contractor, its Affiliates, its subcontractors or their respective
directors, officers, employees, agents or consultants or any other Persons
acting on its or their behalf shall not be cost recoverable as a Petroleum
Operations Cost.
18.1.2
The Contractor shall assume all liability, and exempt the State from any
liability, in respect of any and all claims, obligations, losses, expenses (including
attorneys’ fees), damages or costs of any nature resulting from the violation of
any intellectual property rights of any kind caused by the Contractor, its
Affiliates or subcontractors as a result of or in relation to the conduct of
Petroleum Operations, regardless of the nature of the violation or of the way in
which it may occur.
18.2
Several Liability
Where the Contractor is comprised of more than one Person, the liabilities and
obligations of such Persons under this Contract shall be joint and several,
except for their obligations and liabilities in relation to all taxation assessed on
their income.
18.3
Insurance
18.3.1
The Contractor shall obtain and, during the term of this Contract,
maintain in full force and effect, for Petroleum Operations insurance of such
type and in such amount as is customary and prudent in accordance with
generally accepted practice of the international petroleum industry, and whose
41
coverage terms and conditions shall be communicated to the Ministry within
thirty (30) days after the Effective Date. The foregoing insurance shall, without
prejudice to the generality of the foregoing provisions, cover:
(a)
any loss or damage to all assets used in Petroleum Operations;
(b)
pollution caused in the course of Petroleum Operations;
(c)
property loss or damage or bodily injury or death suffered by any
Person in the course of Petroleum Operations;
(d)
the cost of removing wrecks and clean-up operations following
an accident or upon decommissioning; and
(e)
the Contractor's liability to its employees engaged in Petroleum
Operations.
18.3.2
The Contractor shall require its subcontractors to carry insurance of
such type and in such amount as is customary in accordance with generally
accepted practice of the international petroleum industry.
18.3.3
The Contractor shall use all reasonable endeavors to place the
insurance required under this Article 18 with Equatoguinean insurance brokers
and insurance companies.
ARTICLE 19 - TITLE OF GOODS, EQUIPMENT AND DATA
19.1
Title and Use of Facilities, etcetera
19.1.1
All installations, facilities, goods, equipment, materials or land acquired
by the Contractor for Petroleum Operations shall become property of the State
from the point at which their costs are fully recovered by the Contractor.
However, the Contractor may continue using said installations, facilities, goods,
equipment, materials or land in order to carry out Petroleum Operations for the
duration of this Contract and in accordance with the Hydrocarbons Law. The
Contractor and the Ministry shall agree the mode and conditions of such use,
subject to ensuring their maintenance in good condition and good working
order, normal wear and tear excepted. In any case, upon termination, rescission
or cancellation of this Contract, for any reason whatsoever, in relation to all or
any part of the Contract Area, the ownership of said installations, facilities,
goods, equipment, materials or land, and including those whose costs have not
been fully recovered, and any other items acquired and used for Petroleum
Operations shall become the sole property of the State and shall be conveyed
directly to it.
19.1.2
Regardless of whether or not the Contractor has recovered the relevant
costs in accordance with this Contract, the State is entitled to use the said
facilities, goods, equipment, materials or land for its own purposes, provided
that such use does not interfere with the Contractor’s Petroleum Operations.
19.1.3
Under no circumstances may the Contractor sell, assign, transfer or
otherwise dispose of any such facilities, goods, equipment, materials or land to
any other Persons.
19.1.4
The provisions of this Article 19.1 shall not apply to any leased
equipment or to the Contractor’s equipment that is not charged to Petroleum
Operations as a Petroleum Operations Cost.
42
19.1.5
If the Ministry does not wish to use any of the facilities, goods,
equipment and materials referred to in this Article 19.1, it has the right to
request the Contractor to remove them at the Contractor’s own expense, and
the Contractor will carry out any decommissioning operations of the said
facilities, goods, equipment and materials in accordance with this Contract and
the Hydrocarbons Law, and based on the time frame and specified conditions in
the approved decommissioning plan.
19.2
Ownership of Data
All data, technical information and interpretations obtained, acquired or derived
as a result of Petroleum Operations shall be the sole property of the State.
However, the Contractor may retain copies of all such materials for the duration
of this Contract only, including, among others, geological, geophysical,
petrophysical and engineering reports, Well reports, termination reports,
samples and any other information that the Contractor may have obtained or
compiled during the term of this Contract. The Contractor shall forward such
data, technical information and interpretations to the Ministry as soon as they
are acquired, derived or compiled and shall also provide the Ministry on an
annual basis with a report that itemizes all such data, technical information and
interpretations that have been assembled during the Year. Unless previously
provided, at the termination of this Contract or at any time of relinquishment, the
Contractor shall return to the Ministry all original data, technical information and
interpretations relating to the areas relinquished and will remove all copies of
such from the Contractor’s files, archives, computers and data storage
mechanisms.
ARTICLE 20 - CONFIDENTIALITY
20.1
Disclosure of Confidential Information
20.1.1
The Parties agree that for the duration of this Contract, the terms hereof
and all information relating to this Contract and Petroleum Operations shall be
kept strictly confidential and may not be divulged by any Party without mutual
consent, except:
(a)
to an Affiliated Company;
(b)
to any governmental agency, designated by the State or other
entities or consultants of the Ministry;
(c)
to the extent that such data and information is required to be
furnished in compliance with any applicable laws or regulations;
(d)
in conformity with the requirements of any stock exchange
having jurisdiction over a Party;
(e)
where any data or information forms part of the public domain
otherwise than a result of a breach of this Contract; and
(f)
to employees, directors, officers, agents, advisors, consultants or
subcontractors of a Party comprising the Contractor or an
Affiliate,
43
provided that the disclosing Party shall be responsible for any
and all breaches of this Article by such Persons and provided
further that any disclosure to the Persons referred to in
paragraphs (f), (g) and (h) above shall be limited to those
Persons who are under a duty of confidentiality similar to that
contained in this Article 20.1.
20.1.2
For an additional period of two (2) Years after the termination of this
Contract, only the Parties comprising the Contractor (other than the National
Company) shall be obliged to comply with the above stated requirements.
20.2
The Contractor's Patents
The State shall not reveal to any third parties information pertinent to the
Contractor’s own technology that is protected by patents or contractual
agreements, or which the State has received under license for a period of two
(2) Years after termination of this Contract.
20.3
Continuation of Obligations
Any Party ceasing to own a Participation Interest in this Contract during the
term of this Contract shall nonetheless remain bound by the obligations of
confidentiality set forth in this Article 20.
20.4
Disclosure of Confidential Information by the State and Ministry
In order to explore and exploit areas adjoining or related to the Contract Area,
the State and the Ministry may, notwithstanding this Article 20, disclose to any
third parties all data and information relating to part or parts of the Contract
Area and Petroleum Operations hereunder.
ARTICLE 21 - TERMINATION
21.1
Termination by the State
Notwithstanding any other actions contemplated herein, this Contract may be
terminated, without compensation to the Contractor, on any of the following
grounds:
(a)
a material breach by the Contractor (not attributable to any act or
omission of the State or to any Person representing the State) of
any of the provisions of this Contract or the Hydrocarbons Law;
(b)
a delay by the Contractor (not attributable to any act or omission
of the State or to any Person representing the State) in making
any payment owed to the State that exceeds three (3) months;
(c)
the suspension of Development works on a Field for six (6)
consecutive months, except when such suspension (i) has been
approved by the Ministry in advance or (ii) is due to an act or
omission on the part of the State or of any Person representing
the State or (iii) is as a result of Force Majeure;
44
(d)
when, after the commencement of Production of a Field, its
exploitation is suspended for at least three (3) consecutive
months, without the prior permission of the Ministry, except when
such suspension (i) is due to an act or omission on the part of the
State or of a Person representing the State or (ii) is as a result of
Force Majeure;
(e)
when the Contractor fails to comply
period with an arbitration award
provisions of Article 26, and the
attributable to any act or omission of
representing the State;
(f)
when a Well is drilled to an objective beyond the vertical planes
of the limits of the Contract Area without the prior consent of the
Ministry;
(g)
a breach of this Contract arising out of activities which are illegal
or contrary to national or international law (not attributable to any
act or omission of the State or to any Person representing the
State);
(h)
under the provisions of Article 2.3; or
(i)
when the Contractor is declared bankrupt, or in liquidation as a
result of financial insolvency, or enters into judicial or financial
arrangements on insolvency with its creditors generally, except
when the Contractor can provide the State with a new financial
guarantee that is acceptable to the Ministry in its sole discretion,
and that guarantees the capacity of that Party to fulfill its
obligations under this Contract.
within the prescribed time
in accordance with the
failure to comply is not
the State or to any Person
21.2
Notice of Termination and Grace Period
21.2.1
The Ministry may declare this Contract terminated only after having
served a formal notice on the Contractor, by registered mail, requesting it to
remedy the situation or breach in question, and, if the situation or breach in
question is capable of remedy, requesting it to remedy the same within five (5)
Business Days from receipt of such notice regarding payments due under
Article 21.1(b) or within three (3) months from receipt of such notice for all other
situations or breaches capable of remedy. Otherwise the effective date of the
termination of this Contract shall be date of receipt by the Contractor of the
foregoing notice.
21.2.2
If the Contractor fails to comply with such notice within the prescribed
time period or fails to show within such five (5) Business Days or three (3)
month period that it has commenced and is promptly and diligently continuing to
remedy the situation or breach in question, the Ministry may pronounce ipso
jure the termination of this Contract.
21.3
Termination against one Party
The Ministry may terminate this Contract as to one of the Parties comprising the
Contractor, if the circumstances set forth in Article 21.1 are applicable to only
that Party in the manner set forth in Article 21.2.
45
ARTICLE 22 - UNITIZATION
22.1
Obligation to Unitize
If any Hydrocarbon bearing reservoir lying within the Contract Area extends
beyond such area, the Contractor must carry out all Development and
Production in respect of such Hydrocarbon bearing reservoir in accordance with
the Hydrocarbons Law. The Contractor shall use all reasonable endeavors to
reach a mutually acceptable unitization agreement and program with all other
affected Persons.
22.2
Suspension of Obligations
In the event that Petroleum Operations that are the subject of this Contract are
suspended by reason of negotiations arising in respect to a unitization scenario
in relation to a specific Discovery, the provisions of Article 5.3 for such
Discovery shall be extended for a period of time equal to the duration of such
suspension.
ARTICLE 23 - LOCAL CONTENT AND SOCIAL PROGRAMS
23.1
Preference to Equatoguinean Services
The Contractor and its subcontractors undertake to give preference to
Equatoguinean services, materials, equipment, consumables and other goods
whose quality and time of delivery are comparable to those available
internationally, provided that the cost in Equatorial Guinea is no more than ten
percent (10%) above the cost of similar services, materials, equipment,
consumables and other goods available internationally.
23.2
Employment and Training of Equatoguineans
23.2.1
From the Effective Date, the Contractor shall ensure priority employment
for adequately qualified Equatoguinean personnel in all levels of their
organization, as the employee's skill allows, and as provided for in Article
23.2.2, shall train or contribute in the training of such personnel to enable them
to qualify for any position relating to Petroleum Operations. Expatriate
personnel may only be employed if the Contractor and its subcontractors have
exhausted all possibilities of recruiting adequately qualified Equatoguinean
personnel in the required area of specialization.
23.2.2
During the term of this Contract, the Parties comprising the Contractor
(other than the National Company) shall spend a minimum of [insert amount]
Dollars ($[insert amount]) per Calendar Year, to provide a mutually agreed
number of Ministry and National Company personnel with on-the-job training in
the Contractor's operations in Equatorial Guinea and overseas and/or practical
training at institutions abroad, particularly in the areas of natural earth sciences,
engineering, technology, accounting, economics and other related fields of oil
and gas exploration and exploitation. Additionally, during the term of this
46
Contract, the Parties comprising the Contractor (other than the National
Company) shall transfer to the Ministry a minimum of [insert amount] Dollars
($[insert amount]) per Calendar Year which the Ministry shall use at its sole
discretion to educate and train Equatoguinean personnel selected by the
Ministry at universities, colleges or other training institutions selected by the
Ministry and for other general training and educational purposes.
The above costs will be recoverable as a Petroleum Operations Cost in
accordance with the provisions of this Contract.
23.2.3
If the Contractor funds any social projects outside of those approved in
an Annual Budget such costs shall not be recoverable as a Petroleum
Operations Cost.
23.2.4
Given that Equatoguinean civil society is a part of the local content in oil
and gas contracts, the Contractor shall contribute to and cooperate with nongovernmental organizations in charitable works to develop society, sport
activities and health programs to fight and prevent disease, as well as other
non-profit related activities.
23.3
National Technology Institute
The Contractor shall provide all reasonable assistance as may be requested by
the Ministry from time to time with the implementation and development of the
National Technology Institute to train and develop mid and upper level
personnel in the petroleum industry of Equatorial Guinea and in accordance
with the Hydrocarbons Law.
ARTICLE 24 - DECOMMISSIONING
24.1
Relinquishment or Decommissioning
24.1.1
Subject to Article 2.5.2, the Contractor may at any time relinquish and/or
abandon any portion of the Contract Area or any Well not included in a Field
subject to having given three (3) months prior notice to the Ministry, provided
that the Contractor shall have fulfilled all of its obligations under this Contract
and that it has given the Ministry full details of the state of any reservoir and the
facilities and equipment in such area in addition to any plans for the removal or
dismantling of such facilities and equipment including all technical and financial
information. All decommissioning operations must be undertaken in accordance
with the Hydrocarbons Law.
24.1.2
The decommissioning of a Field by the Contractor and its corresponding
decommissioning plan shall require the prior approval of the Ministry in
accordance with the Hydrocarbons Law. The Contractor shall prepare and
deliver to the Ministry a plan for the decommissioning of all Wells, facilities and
equipment, the rehabilitation of the landscape and the continuation of Petroleum
Operations, if applicable, in accordance with the Hydrocarbons Law.
47
24.1.3
Unless the Ministry elects to keep the facilities and equipment in order to
continue Petroleum Operations in accordance with Article 24.3.3, the Contractor
is obligated to fully decommission all Fields within the Contract Area.
24.2
Right of Ministry
Upon receipt by the Ministry of the notice referred to in Article 24.1.1 or upon
the decommissioning of any Field, the Ministry shall be entitled to take over any
Discovery or Field whose decommissioning is proposed by the Contractor. If the
Ministry does not communicate its desire to take over Petroleum Operations
within three (3) months of receipt of the relevant notice, it shall be deemed to
have elected not to do so.
24.3
Reserve Fund
24.3.1
In order to implement the decommissioning of a Field, the Contractor
shall contribute to a reserve fund for the estimated decommissioning costs, (the
Reserve Fund) in accordance with the Hydrocarbons Law and the approved
decommissioning plan.
24.3.2
In the event that the total amount of the Reserve Fund is greater than
the actual cost of decommissioning, the account balance shall be distributed
between the State and the Contractor in accordance with Article 7.3. In the
event that the amount of the Reserve Fund is less than the actual cost of
decommissioning operations, the Contractor shall be liable for the remainder.
24.3.3
In the event that the Ministry elects to keep the facilities and equipment
in order to continue Petroleum Operations after the withdrawal of the
Contractor, the Reserve Fund so established together with the related interest
shall be put at the Ministry’s disposal to cover the later decommissioning. The
Contractor shall be released from any further decommissioning liability in
respect of such facilities and equipment.
24.4
Continuing Operations
The State undertakes not to interfere with the conduct of Petroleum Operations
in the Contract Area retained by the Contractor in the event that the State
should elect to take over a Discovery or Field pursuant to Article 24.2. If
requested by the Ministry, the Contractor shall undertake to continue all
operations for a fee and on terms to be agreed between the Ministry and the
Contractor.
24.5
Protection of the Environment
The Contractor shall duly plug all the Wells and decommission all facilities and
equipment in order to avoid contamination and harm to the environment and
possible damage to the reservoir, in accordance with the Hydrocarbons Law,
the other laws of Equatorial Guinea and generally accepted practice of the
international petroleum industry.
48
ARTICLE 25 - APPLICABLE LAW
25.1
Applicable Law
This Contract and all Petroleum Operations carried out hereunder shall be
governed by and construed in accordance with the laws of Equatorial Guinea.
ARTICLE 26 - RESOLUTION OF CONFLICTS AND ARBITRATION
26.1
Dispute Resolution and Notification
26.1.1
In the event of any dispute, claim, conflict or controversy (a Dispute)
between any of the Parties arising out of, or in relation to, this Contract,
including any question regarding its breach, existence, validity or termination,
the Parties shall take all reasonable measures to resolve such Dispute
amicably.
26.1.2
If the relevant Parties have not reached an amicable agreement after
three (3) months of the date of the notice of a Dispute by one Party to another,
unless the Parties to the Dispute mutually agree to an extension, any Party to
the Dispute may refer the Dispute for resolution by final and binding arbitration:
26.2
(a)
to the International Centre for the Settlement of Investment
Disputes (the Centre) established by the Convention on the
Settlement of Investment Disputes between States and Nationals
of other States, done at Washington, March 18, 1965 (the ICSID
Convention);
(b)
to the Additional Facility of the Centre, if the Centre is not
available; or
(c)
in accordance with the Arbitration Rules of the United Nations
Commission on International Trade Law (UNCITRAL), if neither
the Centre or the Additional Facility are available.
Seat and Language of Arbitration
The seat of the arbitration shall be agreed by the Parties to the Dispute and, in
case of a disagreement, shall be determined by the arbitrators. The languages
of the arbitration proceedings, and of all orders, decisions, and the award, shall
be Spanish and English.
26.3
Number and Identity of Arbitrators
The arbitral tribunal shall be constituted by three (3) arbitrators selected
according to the following procedure:
(a)
The claimant and the respondent shall, within thirty (30) days
from the day on which a request for arbitration has been
submitted, appoint an arbitrator each (and if there is more than
one claimant or more than one (1) respondent, then the
claimants and/or the respondents collectively shall each appoint
a single arbitrator), by giving notice in writing of such
49
appointment to the Secretary-General of ICSID and the other
Party or Parties to the Dispute.
(b)
If either the claimant or the respondent fails to comply with the
time limit in the preceding paragraph, the Chairman of the
Administrative Council of ICSID shall appoint the arbitrator or
arbitrators that have not yet been appointed, at the request of
either the claimant or the respondent and after consulting the
claimant and the respondent as far as possible. The Chairman of
the Administrative Council of ICSID shall give notice in writing of
such appointment or appointments to the Secretary-General of
ICSID and the claimant and the respondent.
(c)
The two (2) arbitrators so appointed shall, within thirty (30) days
of their appointment agree upon the person to be appointed as
the President of the tribunal, and give notice of such appointment
to the Secretary-General of ICSID and the claimant and the
respondent.
(d)
If the two (2) arbitrators fail to agree upon the person of the
President of the tribunal, the Chairman of the Administrative
Council of ICSID shall appoint the President, at the request of
either the claimant or the respondent, and after consulting the
claimant and the respondent as far as possible. The Chairman of
the Administrative Council of ICSID shall give notice in writing of
such appointment to the Secretary-General of ICSID and the
claimant and the respondent.
None of the arbitrators shall be a citizen of the countries of any of the Parties to
the Dispute (or in the case where the Party is a company or another entity, any
country or countries of nationality of such Party, including the country of its
ultimate parent).
26.4
Rules of Arbitration
The arbitration procedures initiated under this Contract shall operate under the
arbitration rules in effect for ICSID, the Additional Facility or UNCITRAL, as the
case may be, at the time of the filing of the request for arbitration, which rules
are deemed to be incorporated herein by reference in this Article 26.
26.5
Binding Nature of Arbitration
The arbitration award shall be final and binding on the Parties and shall be
immediately enforceable, subject to the remedies provided for in the ICSID
Convention and Arbitration Rules, in the Arbitration Rules of the Additional
Facility of the Centre, or in the UNCITRAL Arbitration Rules, as appropriate.
The Parties waive any right to refer any question of law, and any right of appeal
on the law and/or merits to any court. It is expressly agreed that the arbitrators
shall have no authority to award aggravated, exemplary or punitive damages.
26.6
Costs of Arbitration
The costs of arbitration shall be charged in accordance with the directions of the
arbitration tribunal, failing which shall be borne proportionally by the Parties to
50
the Dispute on a per capita basis. The costs of the Parties comprising the
Contactor shall not be recoverable.
26.7
Payment of Awards
Any monetary award issued shall be expressed and payable in Dollars.
ARTICLE 27 - FORCE MAJEURE
27.1
Non-fulfillment of Obligations
Any obligation or condition arising or derived from this Contract which any Party
is unable to perform, whether in whole or in part, shall not be considered as a
breach or non-fulfillment of its obligations under this Contract if such breach or
non-performance is caused by an event of Force Majeure, provided that there is
a direct cause-and-effect relationship between the non-performance and the
event of Force Majeure. Notwithstanding the foregoing, all payment obligations
owed by any Party to another must be made when due.
27.2
Definition of Force Majeure
For the purposes of this Contract, an event shall be considered an event of
Force Majeure if it meets the following conditions:
(a)
it has the effect of temporarily or permanently preventing a Party
from performing its obligations under this Contract;
(b)
it is unforeseeable, unavoidable and beyond the control of the
Party which declares Force Majeure; and
(c)
it is not a result of the negligence or willful misconduct of the
Party which declares Force Majeure.
Such an event shall include acts of God, earthquake, inclement weather, strike,
riot, insurrection, civil unrest, blockade, sabotage and acts of war (whether
declared or not). The Parties intend for the term of Force Majeure to be
construed in accordance with the principles and practice of the international
petroleum industry.
27.3
Notification of Force Majeure
If any Party is unable to comply with any obligation or condition provided herein
due to Force Majeure, it shall notify the other Parties in writing as soon as
possible, and in any event not later than fourteen (14) days after the event in
question, giving the reason for its non-compliance and a detailed account of the
Force Majeure, as well as the obligation or condition affected. The Party
affected by the Force Majeure shall use all reasonable endeavors to remove the
cause thereof, keep the other Parties fully informed of the situation and the
current evolution of the Force Majeure event and shall promptly notify the other
Parties as soon as the Force Majeure event is over and no longer prevents it
from complying with its obligations or conditions hereunder.
51
27.4
Continuation of Obligations
All obligations, other than those affected by the event of Force Majeure, shall
continue to be performed in accordance with this Contract.
27.5
Cessation of Force Majeure
Upon the cessation of the event of Force Majeure, the relevant Party shall
undertake and complete, as soon as practicable and within a time frame to be
mutually agreed by the Parties, all obligations suspended as a result thereof.
27.6
Continuation of Force Majeure
When a Force Majeure event lasts more than ninety (90) days, the Parties will
forthwith consult to examine the situation and implications for Petroleum
Operations, in order to establish the course of action appropriate for the
fulfillment of contractual obligations under the circumstances of the said Force
Majeure. In such event the term of this Contract will be extended by the same
amount of time that the Force Majeure has lasted.
ARTICLE 28 - ASSISTANCE AND NOTICES
28.1
Assistance of Ministry
28.1.1
The Ministry shall facilitate, within its authority and in accordance with
the rules and procedures in effect in Equatorial Guinea, the performance of the
Contractor’s activities by granting it all permits, licenses and access rights that
are reasonably necessary for the purposes of Petroleum Operations, and by
making available to it all necessary services with respect to Petroleum
Operations in Equatorial Guinea.
28.1.2
The Ministry shall also facilitate and assist the Contractor in obtaining all
permits, licenses or rights not directly related to Petroleum Operations, but
which the Contractor may reasonably require for the purposes of fulfilling its
obligations under this Contract.
28.2
Notices and Other Communications
All notices, approvals or other communications authorized or required between
the Parties by any of the provisions of this Contract shall be in writing (in
Spanish and English), addressed to such Parties and delivered in person by
courier service or by any electronic means of transmitting written
communications which provides written confirmation of complete transmission.
For purposes of this Contract, oral communication does not constitute notice or
approval, and e-mail addresses and telephone numbers for the Parties are
listed below as a matter of convenience only. A notice or approval given under
any provision of this Contract shall be deemed delivered only when actually
received by the Party to whom such notice or approval is directed, and the time
for such Party to deliver any communication in response to such originating
notice or approval shall run from the date the originating notice or approval is
received. Each Party shall have the right to change its address at any time
and/or designate that copies of all such notices or approvals be directed to
52
another Person at another address, by giving written notice thereof to all other
Parties.
For the State:
MINISTRY OF MINES, INDUSTRY AND ENERGY
Calle
Malabo, Bioko Norte
Republic of Equatorial Guinea
For the attention of: His Excellency the Minister of Mines, Industry and Energy
Telephone: + (240) 09 3567, 09 3405
Facsimile: + (240) 09 3353
For the Contractor:
[The Company]
For the attention of: [insert name]
Telephone: [insert number]
Facsimile: [insert number]
For the National Company:
The National Company
Calle
P.O. Box 965
Malabo
Guinea Ecuatorial
For the attention of: Director General
Telephone: + (240) 09 6769
Facsimile: + (240) 09 6692
ARTICLE 29 - MISCELLANEOUS
29.1
Amendments
This Contract may only be amended in writing and by mutual agreement
between the Parties; any purported amendments in contravention of this
provision shall not be effective.
53
29.2
No Partnership
This Contract shall not be construed to create an association, joint venture or
partnership between the Parties or to impose any partnership obligation or
liability upon a Party.
29.3
29.3 Hydrocarbons Law
All Petroleum Operations and the Contractor are subject to the provisions of the
Hydrocarbons Law and the Petroleum Regulations in effect from time to time.
29.4
Entire Agreement
With respect to the subject matter contained herein, this Contract (i) is the entire
agreement of the Parties and (ii) supersedes all prior understandings and
negotiations of the Parties.
29.5
No Waiver
In the event of a waiver by any Party of one or more defaults by another Party in
the performance of the provisions of this Contract, such waiver shall not operate
or be construed as a waiver of any future default or defaults by the same Party,
whether of a like or of a different character. Except as expressly provided in this
Contract no Party shall be deemed to have waived, released or modified any of
its rights under this Contract unless such Party has expressly stated, in writing,
that it does waive, release or modify such right.
29.6
No Conflict
29.6.1
Each of the Parties constituting the Contractor undertakes that it shall
avoid any conflict of interest between its own interests (including the interests of
Affiliates) and the interests of the other Parties in connection with activities
contemplated under this Contract.
29.6.2
In the event of any conflict between the main body of this Contract and
its Annexes, the main body shall prevail. In the event of any conflict between
this Contract and the Hydrocarbons Law, the Hydrocarbons Law shall prevail.
ARTICLE 30 - INTERPRETATION
54
30.1
The table of contents and headings used in this Contract are for
convenience only and shall not be construed as having any substantive
significance or as indicating that all of the provisions of this Contract
relating to any topic are to be found in any particular Article.
30.2
Reference to the singular includes a reference to the plural and vice versa.
30.3 Reference to any gender includes a reference to all other genders.
30.3
Unless otherwise provided, reference to an Article or an Annex means an
Article or Annex of this Contract.
30.4
The words include and including shall mean include or including without
limiting the generality of the description preceding such term and are
used in an illustrative sense and not a limiting sense.
30.5
Any reference to a Person shall be construed as including a reference to
its successors, permitted transferees and permitted assignees.
30.6
Any reference to a statute or enactment shall be construed as a reference
to such statute or enactment as it may have been or may be amended or
re-enacted from time to time, or any subordinate legislation made or legal
norm created, or may from time to time be done, under such statute or
enactment.
30.7
Reference to this Contract or part thereof or any other document shall be
construed as a reference to the same as it may be amended,
supplemented, novated or replaced from time to time.
ARTICLE 31 - EFFECTIVE DATE
This Contract shall become effective upon the date the Contractor receives
notification in writing of its ratification by the President of Equatorial Guinea.
55
IN WITNESS WHEREOF, the Parties have executed this Contract in [insert number]
([insert number]) originals in the Spanish language and [insert number] ([insert
number]) originals in the English language. In the event of any conflict, the Spanish
version shall prevail.
THE REPUBLIC OF EQUATORIAL GUINEA
THE MINISTRY OF MINES, INDUSTRY AND ENERGY
Signature: ___________________________
Name: H.E Señor Don _________________
Title: Minister of Mines, Industry and Energy
THE NATIONAL COMPANY
Signature: ____________________________
Name: Don ___________________________
Title: Director General
THE CONTRACTOR
[THE COMPANY]
Signature: ___________________________
Name: ______________________________
Title: ________________________________
56
ANNEX A - CONTRACT AREA
This Annex is an integral part of this Contract between the Republic of Equatorial
Guinea and the Contractor.
Upon the Effective Date, the initial Contract Area covers an area deemed equal to
[insert number] ([insert number]) square kilometres (km2) or [insert number]
([insert number]) hectares for the purposes of Article 11.4.
The Contract Area is described on the map in Annex B. The points indicated on such
map are defined below, by reference to the Greenwich meridian and their geographic
co-ordinates:
Point
Longitude
57
Latitude
ANNEX B - MAP OF THE CONTRACT AREA
This Annex is attached to this Contract between the Republic of Equatorial Guinea and
the Contractor and forms an integral part of the same.
This map is included for illustrative purposes only and in the event of any discrepancies
or conflict, the Contract Area shall be defined by the geographical co-ordinates
specified in Annex A.
58
ANNEX C - ACCOUNTING PROCEDURE
This Annex is an integral part of the Contract between the Republic of Equatorial
Guinea and the Contractor.
59
ARTICLE 1 - GENERAL PROVISIONS
1.1
PURPOSE
The object of this Accounting Procedure is to establish equitable criteria and
methods of calculation and accounting applicable to the provisions of the
Contract, and in particular when:
1.2
(a)
classifying and defining Petroleum Operations Costs; and
(b)
prescribing the manner of preparing and submitting the financial
statements of the Contractor in accordance with accounting principles in
effect in Equatorial Guinea.
INTERPRETATION
For the purposes of this Accounting Procedure, the terms used herein and
which are defined in the Contract shall have the same meaning when used in
this Accounting Procedure. In the event of any discrepancy or conflict between
the provisions of this Accounting Procedure and any other provisions of the
Contract, the provisions of the Contract shall prevail.
1.3
ACCOUNTING RECORDS AND REPORTS
1.3.1
In accordance with the provisions of Article 16.1 of the Contract, the Contractor
shall maintain in its office in Equatorial Guinea original, complete, true and
correct accounts, books and records of the Production and disposition of
Hydrocarbons, and all costs and expenses under the Contract, as well as all
other records and data necessary or proper for the settlement of accounts in
accordance with the laws of Equatorial Guinea, generally accepted accounting
procedures and generally accepted practice in the international petroleum
industry and pursuant to the chart of accounts agreed pursuant to Article 1.3.2
below.
1.3.2
Within sixty (60) days from the Effective Date, the Contractor shall submit to
and discuss with the Ministry a proposed outline for the chart of accounts and
the books, records and reports in accordance with generally accepted
standards and consistent with normal petroleum industry practices and
procedures.
Within sixty (60) days of receiving the above proposal, the Ministry shall either
provide notice of its approval of the proposal, or shall request revisions of such
chart of accounts in writing.
Within one hundred and eighty (180) days after the Effective Date, the
Contractor and the Ministry shall agree on the outline of the chart of accounts,
books, records, and reports which shall describe the basis of the accounting
system and procedures to be developed and used in accordance with this
Accounting Procedure. Following such agreement, the Contractor shall
immediately prepare and provide the Ministry with formal copies of the detailed
and complete chart of accounts and manuals related to the procedures, and a
list of the data and records to be accounted for, recorded, reported and to be
followed under the Contract.
60
1.3.3
In addition to the generality of the foregoing, the Contractor shall submit to the
Ministry, at regular intervals, statements relating to the Petroleum Operations,
including, but not limited to, the following:
(a)
monthly statement of Production;
(b)
quarterly statement of value of Production and pricing;
(c)
statement of Petroleum Operations Costs;
(d)
annual statement of Petroleum Operations Cost not yet recovered;
(e)
statement of Production sharing;
(f)
annual end-of-year statement;
(g)
Annual Budget tracking statement; and
(h)
statement of tangible goods subject to depreciation.
1.3.4
All reports and statements shall be prepared in accordance with the Contract,
the laws of Equatorial Guinea and any regulations thereunder and in
accordance with generally accepted practice of the international petroleum
industry.
1.4
LANGUAGE AND UNIT OF ACCOUNT
Unless otherwise agreed all accounts, records, books and reports shall be
prepared and maintained in Spanish and English and shall be denominated in
Dollars. Additionally, Contractor may maintain accounts and records in other
languages and currencies for information purposes only.
1.5
VERIFICATION AND AUDIT RIGHTS OF THE STATE
1.5.1
When the Ministry exercises its right of audit under Article 16.3 of the Contract,
it shall provide notice to the Contractor, at least sixty (60) days in advance
regarding such audit, which shall take place during normal business hours. The
Contractor shall make available to the Ministry all accounts, books, records,
invoices, cash vouchers, debit notes, price lists or any other documentation
relating to Petroleum Operations. Furthermore, the auditors shall have the right,
in connection with such audit, to visit and inspect at reasonable times any of the
Contractor’s sites, plants, facilities, warehouses and offices which affect
Petroleum Operations directly or indirectly and to question personnel
associated with those Operations.
The Contractor shall endeavor to provide records and accounts from any of its
Affiliates or other Persons necessary to support charges from them. If an
Affiliate or any other Person considers such information confidential or
proprietary, the Ministry may select an internationally recognized independent
firm of public accountants to carry out an audit, subject to the approval of the
Affiliate or other Person, such approval not to be unreasonably withheld or
delayed.
61
If the Ministry does not conduct an audit within the time stipulated in
accordance with Article 16.3 of the Contract, the Contractor’s accounts, books
and records shall be deemed correct and final.
1.5.2
Any audit exceptions shall be made in writing and notified to the Contractor
within ninety (90) days of completion of the corresponding audit. Failure to give
such exception by the Ministry shall be deemed to be an acknowledgement of
the accuracy of the Contractor's books and accounts.
1.5.3
If the Contractor fails to respond to any notice of exception under Article 1.5.2
within ninety (90) days of receipt of such notice, the results of the audit will be
considered valid and accepted by the Contractor. After the said period of time
the Ministry’s exception shall prevail.
1.5.4
Any adjustments resulting from an audit shall be promptly applied to the
Contractor's accounts; any adjustments to payments due shall also be effected
promptly.
1.5.5
If the Contractor and the Ministry are unable to reach final agreement on the
proposed audit adjustments they shall resolve the dispute in accordance with
the provisions of Article 16.3.3 of the Contract.
When audit related issues are still outstanding, the Contractor shall preserve
any relevant documents and allow the Ministry access to them until the issue is
finally resolved.
1.6
CURRENCY EXCHANGE RATES
The exchange rate shall be determined monthly, based on the arithmetic
average of the closing buy and sell rates for the Dollar against the CFA
(Communaute Financiere Africaine or Africa Financial Community) currency
unit for the month, as published by the Bank of Central African States (BEAC).
The exchange rate of the preceding calendar month shall be used for exchange
transactions and for the purpose of determining the counter value of Dollars in
the Equatoguinean currency unit for the next month.
1.7
ACCOUNTING BASIS
All books and accounts shall be prepared on an accrual accounting basis.
Revenues shall be posted to the accounting period in which they were earned,
without any need to recognize whether a given transaction results in a
disbursement or cash receipt. Expenses and costs shall be regarded as
incurred, in the case of physical items, during the accounting period in which
the relevant title is transferred to the Contractor and in the case of services
during the accounting period in which such services are rendered.
1.8
REVIEW OF ACCOUNTING PROCEDURE
By mutual agreement between the Ministry and the Contractor, this Accounting
Procedure may be revised periodically by a document in writing executed by the
Parties.
62
ARTICLE 2 - GENERAL CLASSIFICATION OF PETROLEUM COSTS
All costs related to Petroleum Operations shall be classified in accordance with their
end use. Classification criteria shall be included in the approved Annual Work Program
and Annual Budget for the Calendar Year in which the expenditure is made. All
Petroleum Operations Costs shall be classified, defined and allocated as set forth
below.
2.1
EXPLORATION COSTS
Any and all direct, general and administrative costs incurred during Hydrocarbon
Exploration and Appraisal activities in an area which is part of the Contract
Area, including but not limited to:
2.2
(a)
aerial, geophysical, geochemical, palaeontological, geological,
topographical and seismic surveys and studies and their interpretation;
(b)
core hole drilling;
(c)
any labor, materials, supplies, and services used in drilling Exploration
Wells and Appraisal Wells;
(d)
any facilities used solely in support of the purposes described in
paragraphs (a), (b) and (c) above, including access roads and acquired
geological and geophysical data, all separately identified;
(e)
any other cost incurred in the Exploration and Appraisal of Hydrocarbons
after the Effective Date but prior to the date of approval of a
Development and Production Plan with respect to the relevant Field and
not covered under Articles 2.2, 2.3 and 2.4 below; and
(f)
the costs incurred prior to the Effective Date which both Parties have
agreed to, including the cost of the SBL, 2D, 3D speculative data and
other costs of complying with Article 3.1.1 of the Contract.
DEVELOPMENT AND PRODUCTION COSTS
Development and Production Costs are all approved direct, general and
administrative costs incurred during Development and Production activities,
including, but not limited to, the following:
63
2.3
(a)
drilling Wells defined as Development Wells for purposes of producing
from a Commercial Field, whether such Wells turn out to be dry or
productive by nature, and drilling Wells for the injection of water or gas
to enhance Hydrocarbon recovery;
(b)
completing Wells by way of installation of casing or equipment or
otherwise after a Well has been drilled for the purpose of bringing the
Well into use as a Development Well or a Well for the injection of water
or gas to enhance Hydrocarbon recovery;
(c)
transportation and installation of tank storage facilities, pipelines, flow
lines, production and treatment units, wellhead equipment, subsurface
equipment, enhanced recovery systems, offshore platforms, export
terminals and piers, harbors and related facilities, and access roads for
development activities; and
(d)
engineering and design studies for facilities referred to under paragraph
(c) above.
OPERATING OR PRODUCTION COSTS
Any and all general, administrative and service costs, and any other Petroleum
Operations Costs incurred from the approval date of any relevant Development
and Production Plan, and from the commencement of funding of the Reserve
Fund.
2.4
COMMERCIALIZATION COSTS
Any and all costs incurred for exporting Hydrocarbons to the Delivery Point.
2.5
ALLOCATION OF GENERAL AND ADMINISTRATIVE COSTS
With the exception of general and administration costs incurred in Equatorial
Guinea directly assignable to the Annual Budget, the general and administration
expenditures incurred by the Contractor outside of national territory with respect
to Petroleum Operations shall be determined in accordance with the sliding
scale set out below, based on total Petroleum Operations Costs actually
incurred during the Year and duly justified by the Contractor and approved by
the Ministry:
(a)
Prior to commercial Production:
Up to [insert amount] Dollars
${insert amount]
●%
Next [insert amount] Dollars
${insert amount]
●%
Next [insert amount] Dollars
${insert amount]
●%
●%
Balance
64
(b)
After commercial Production:
Up to [insert amount] Dollars
${insert amount]
●%
Next [insert amount] Dollars
${insert amount]
●%
Next [insert amount] Dollars
${insert amount]
●%
●%
Balance
2.6
Except as provided otherwise in the Contract to the contrary, approved
Petroleum Operation Costs described in Articles 2.1 to 2.5 of this Accounting
Procedure, will be recoverable by the Contractor in accordance with Article 7.2
of the Contract.
2.7
INTEREST RECOVERY
Subject to and in accordance with the Hydrocarbons Law, any interest on loans
obtained by the Contractor from Affiliated Companies shall not be recoverable
as a Petroleum Operations Cost, nor shall it be deductible for tax purposes
when estimating any Income Tax liabilities of the Contractor. Any interest on
loans obtained by the Contractor from Persons other than Affiliated Companies
for investments in Petroleum Operations shall not be recoverable as a
Petroleum Operations Cost but shall be deductible for tax purposes, when
estimating any Income Tax liabilities of the Contractor provided that the rate of
interest and the terms of repayment have been approved by the Ministry in
advance.
2.8
NON RECOVERABLE COSTS
Costs that are not recoverable as Petroleum Operations Costs shall include the
following:
65
2.9
(a)
signature bonus paid by the Contractor;
(b)
any Discovery bonus paid by the Contractor;
(c)
any Production bonus paid by the Contractor;
(d)
annual surface rentals paid to the State;
(e)
interests on loans as provided by Article 2.7 of this Accounting
Procedure;
(f)
any unapproved over-expenditures that exceed the limits of Article 4.4 of
this Contract;
(g)
any payments made to the State for failure to fulfill the minimum
Exploration work obligations pursuant to Article 3 of the Contract;
(h)
any fines and sanctions incurred for infringing the laws and regulations
of Equatorial Guinea;
(i)
any donation to the State or other similar expenses unless otherwise
agreed;
(j)
the State’s audit and inspection expenses incurred as a result of the
absence of original documents in the Contractor’s offices in Equatorial
Guinea;
(k)
any sanction imposed on the Contractor under the Hydrocarbons Law or
otherwise; and
(l)
costs related to the assignment from the Contractor to any of its Affiliates
or other Persons.
INSURANCE AND CLAIMS
Petroleum Operations Costs shall include premiums paid for insurance required
[and approved] in accordance with the Contract. All expenses incurred and paid
by the Contractor in respect of any insurance claim, less any costs recovered by
the Contractor by means of insurance claims, shall be included and recoverable
as Petroleum Operations Costs, provided these expenses are not incurred as a
consequence of their being not recoverable under a policy of insurance of the
Contractor, in which case they shall not be recoverable.
2.10
INVENTORY ACCOUNTING
Any costs of articles bought for inventory will be recoverable as from the
Calendar Year in which such materials and equipment have been used in the
Petroleum Operations in the Contract Area.
66
ARTICLE 3 - OTHER CLASSIFICATION OF COSTS AND EXPENDITURES
(Accounting Methods For Estimating Any Income Tax Liability)
During any Calendar Year in which commercial Production occurs, the
Petroleum Operations Costs shall include the following:
3.1
CAPITAL COSTS
Any current Calendar Year capital costs shall be classified as Tangible (subject
to depreciation) and Intangible.
3.1.1
TANGIBLE CAPITAL COSTS
Tangible Capital Costs are such costs that are not intangible capital costs
incurred for the purchase of any assets related to the Petroleum Operations that
normally have a useful life of more than one (1) Year; such assets shall be
subject to annual depreciation pursuant to the provisions set forth in this
Accounting Procedure. Tangible Capital Costs include the following:
(a)
for Development Wells: the costs of completion materials and equipment
(downhole equipment, fixed production tubing, production packers,
valves, wellhead equipment, subsoil elevation equipment, pumping rods,
surface pumps, discharge cables, collection equipment, delivery lines,
fixed Christmas tree and valves, oil and gas pipelines, fixed materials
and equipment, piers, anchors, buoys, Hydrocarbon treatment facilities
and equipment, secondary recovery systems, reinjection compressors,
water pumps and their pipes);
(b)
for any purchase of goods and equipment: the actual cost of the asset
(excluding transportation), the cost for construction of platforms outside
of the Contract Area, the cost of power generators and facilities onshore;
(c)
for the purchase of moveable goods: automotive machinery (vehicles,
tractors, tow trucks, tools, flatbeds, etc.), construction machinery and
equipment (furniture, office equipment and other equipment);
(d)
for construction purposes: the building cost of housing and residential
facilities, offices, warehouses, workshops, power plants, storage
facilities and access roads for development activities, the cost of piers
and anchors, treatment plants and machinery, secondary recovery
systems, gas plants and steam systems; and
(e)
drilling and Production facilities and platforms.
With the exception of land purchased by the Contractor, all and any
goods mentioned herein shall be depreciated in accordance with Article
3.2 of this Accounting Procedure.
67
3.1.2
INTANGIBLE CAPITAL COSTS
Intangible capital costs shall be such ongoing costs incurred for the purchase of
moveable assets and services directly related to the Petroleum Operations and
they shall not be depreciated. Such costs/expenses shall include the following:
3.2
(a)
costs of aerial magnetic, aerial gravimetric, topographic, geological,
geophysical and geochemical surveys, interpreting and reinterpreting
technical data costs, Exploration labor and similar costs;
(b)
costs of drilling Exploration Wells and Appraisal Wells: all costs of
services rendered for drilling Exploration and Appraisal Wells, chemical
products, rental costs (for helicopters, flatbeds, ships, tow barges, etc.)
transportation, storage facilities, accommodation, technical services for
mud control, Well geology, directional Well drilling, divers, mud control,
well geology testing, cementing and similar costs;
(c)
costs of drilling Development Wells, such as rig and platform
mobilization and demobilization, rig and platform drilling contracts and
leases, platform and infrastructure installations labor, fuel, water,
conductors, drill bits, drill pipe, equipment rental, production testing
equipment, Christmas tree for production testing, mud and its
components, chemical products, rental costs (for helicopters, flatbeds,
ships, tow barges, etc.), transportation, storage facilities,
accommodation, technical services for mud control, Well placement
geology, directional drilling Wells, divers, production and appraisal tests,
completion and supervision;
(d)
costs of acquisition or purchase of goods and services such as
transportation costs, operation costs, equipment checks, costs of on-site
installation, maintenance costs and fuel costs;
(e)
general services (electric logs, vertical seismic profile (VSP), mud
control, core sampling, Well geology tests, cementing, production tests,
supervision and similar costs), delineation services, any heavy
engineering machinery leasing, and other expenses incurred abroad;
(f)
materials, reconstruction of access and other roads, and other intangible
goods for construction, public services and construction support; and
(g)
other Exploration Costs, support or temporary facilities with a useful life
of less than one (1) Year.
DEPRECIATION OF TANGIBLE CAPITAL COSTS
Depreciation will be estimated from the Calendar Year in which the asset is
placed into service, with a full Year's depreciation allowed for the initial
Calendar Year. For the purpose of estimating responsibility regarding Income
Tax, depreciation shall be determined using a ten (10) Year straight-line
method.
3.3
3.3 NON-CAPITAL COSTS
Non-capital costs shall be classified as follows:
68
3.3.1
CONTRACTOR’S DEDUCTIBLE COSTS
For Income Tax purposes, the Contractor's deductible costs shall include the
following:
3.3.2
(a)
general and administrative expenses (personnel salaries, insurance
premiums, labor, technical office services and other similar services,
material services, public relations, expenses abroad related with
Petroleum Operations in Equatorial Guinea, determined in accordance
with Article 2.5 of this Accounting Procedure);
(b)
labor, materials and services indirectly used in operations of
Development Wells, feasibility studies for production of Crude Oil or
Natural Gas fields, secondary recovery operations, storage operations,
handling, transportation and delivery, Natural Gas Well operations,
transportation and delivery of Natural Gas, services for Natural Gas
treatment, environmental protection measures and any other
maintenance activities indirectly related to Petroleum Operations.
CONTRACTOR’S NON-DEDUCTIBLE COSTS
For Income Tax purposes, the following costs of the Contractor shall be nondeductible:
69
(a)
signature bonus paid by the Contractor;
(b)
any Discovery bonus paid by the Contractor;
(c)
any Production bonus paid by the Contractor;
(d)
annual surface rentals paid to the State;
(e)
any unapproved over-expenditures that exceed the limits of
Article 4.4 of the Contract;
(f)
interest on loans as provided in Article 2.7 of this Accounting
Procedure;
(g)
any payment made to the State for failure to fulfill the minimum
Exploration work obligations pursuant to Article 3 of the Contract;
(h)
any fines and sanctions incurred for infringing the laws and
regulations of Equatorial Guinea;
(i)
sums that exceed the set limits with regard to the depreciation of
tangible assets;
(j)
any donation to the State and other similar expenses unless
otherwise agreed;
(k)
the State's audit and inspection expenses incurred by the
absence of original documents in the office of the Contractor in
Equatorial Guinea;
(l)
any sanction imposed on the Contractor under the Hydrocarbons
Law or otherwise; and
(m)
costs relating to the assignment from the Contractor to any of its
Affiliates or other Persons.
70
ARTICLE 4 - ARTICLE 4 BASES OF INCOME TAX CALCULATION
4.1
PRACTICAL DETERMINATION OF THE TAXABLE BASE
In order to determine the taxable base and for the purposes of calculating the
Contractor’s responsibility regarding annual Income Tax liability, the following
will be taken into account:
Taxable base = [(1)] – { [(2)+(3)+(4)]+[(5)+(6)+(7)+(8)] }.
1. Annual gross revenues
2. Royalties
3. State’s share of net Hydrocarbons
4. State’s right to a share of Production based on its carried or paid
interest in the Contract
5. Deductible intangible capital costs
6. Depreciation of tangible capital costs
7. Deductible non-capital costs
8. (8) Losses authorized and certified by the Ministry, corresponding to
previous Calendar Years
4.2
PRINCIPLE OF TAX TREATMENT OF A FINANCIAL YEAR DEFICIT
In case of any deficit during a Calendar Year, such deficit will be regarded as
relating to the following Calendar Year and deducted from the profit made
during said Calendar Year; if such profit is not sufficient for the deduction to be
made in full, the excess (certified by the Ministry) of the deficit will be
successively carried over to the profits of the following Calendar Year.
71
ARTICLE 5 - RECORDS AND VALUATION OF ASSETS
5.1
RECORDS
The Contractor shall keep correct, accurate and detailed records of all property
used for Petroleum Operations under the Contract in accordance with generally
accepted practice of the international petroleum industry.
5.2
INVENTORIES DURING INITIAL EXPLORATION OPERATIONS
Prior to the date of approval of the first Annual Work Program and Annual
Budget submitted pursuant to Article 4 of the Contract, the Contractor shall
prepare an initial annual schedule (to be included as part of the material
statement required under Article 6 of this Accounting Procedure) of all property
to be used for Petroleum Operations and its value as shown in the Contractor’s
books.
5.3
INVENTORIES IN SUBSEQUENT OPERATIONS
Subsequent to the date of approval of the Annual Work Program and Annual
Budget pursuant to Article 4 of the Contract, inventories of property used in
Petroleum Operations under the Contract shall be taken at regular intervals but
at least once per Calendar Year.
The Contractor shall give the Ministry at least thirty (30) days prior notice of its
intention to take such inventory and the Ministry shall have the right to be
represented when such inventory is taken. The Contractor shall clearly state the
principles upon which valuation of the inventory has been based and shall
provide to the Ministry a full report on such inventory within sixty (60) days of
the completion of the inventory.
72
ARTICLE 6 - STATEMENTS AND REPORTS
6.1
FINANCIAL STATEMENTS AND TAX REPORTS TO BE SUBMITTED BY
CONTRACTOR
The Contractor shall present detailed accounts showing all Petroleum
Operations Costs incurred by the Contractor over the last Calendar Year. Such
accounts must be submitted to the Ministry within ninety (90) days from the end
of such Calendar Year and shall be certified by an independent auditor
accepted by the Parties. Such period may be extended by an additional thirty
(30) days at the Contractor's request and with the approval of the Ministry; such
consent shall not be unreasonably delayed or withheld.
Income Tax returns shall be duly completed with enough detailed information as
to allow a thorough understanding by the Tax Administration of Equatorial
Guinea, including:
6.2
(a)
depreciation details;
(b)
fixed assets information;
(c)
Production and export statistics and details;
(d)
all tax related reports provided for in the Contract; and
(e)
detailed information on deductible expenses for estimating tax liabilities
in accordance with the Tax Law.
PRODUCTION STATEMENT
Without prejudice to the rights and obligations of the Parties under the Contract,
as from the initial date of commencement of commercial Production from the
Contract Area, the Contractor shall submit a monthly Production statement to
the Ministry showing the following information, which shall be separated by
each Commercial Field as well as in aggregate for the Contract Area:
73
(a)
the quantity of Crude Oil produced and saved;
(b)
the quality characteristics of such Crude Oil produced and saved;
(c)
the quantity of Natural Gas produced and saved;
(d)
the quality characteristics of such Natural Gas produced and saved;
(e)
the quantities of Crude Oil and Natural Gas used for the purposes of
carrying out drilling and Production operations;
(f)
the quantities of Crude Oil and Natural Gas unavoidably lost;
(g)
the quantities of Natural Gas flared and vented;
(h)
the size of Hydrocarbon stocks held at the beginning of the calendar
month in question;
(i)
the size of any Hydrocarbon stocks held at the end of the calendar
month in question;
(j)
the quantities of Natural Gas re-injected into the Hydrocarbon reservoir;
and
(k)
the quantities of Hydrocarbons delivered and sold.
All quantities shown in such statement shall be expressed in both volumetric
terms (barrels of Crude Oil [bbls] and cubic meters of Natural Gas [M3]) and in
weight (metric tons [MT] and long tons [LT]).
The Production statement for each calendar month, and the technical report on
each Well shall be submitted to the Ministry no later than a period of fifteen (15)
days after the end of such calendar month.
6.3
VALUE OF PRODUCTION AND PRICING STATEMENT
For the purposes of Article 10 of the Contract, the Contractor shall prepare a
Quarterly statement providing details of the value of Hydrocarbons produced,
saved and sold during each Quarter.
The value of Production statement shall include the following information:
74
(a)
the quantities, prices and income received by the Contractor as a result
of sales of Hydrocarbons to third parties during the Quarter in question;
(b)
the quantities, prices and income received by the Contractor as a result
of sales of Hydrocarbons, other than sales to third parties, during the
Quarter in question;
(c)
the value of any stocks of Hydrocarbons at the end of the Quarter
preceding the Quarter in question;
(d)
the value of any stocks of Hydrocarbons at the end of the Quarter in
question; and
(e)
the information available to the Contractor concerning the prices of
competitive Crude Oils, insofar as required for the purposes of Article 10
of the Contract.
6.4
PETROLEUM OPERATIONS COSTS STATEMENT
6.4.1
Quarterly Statement
The Contractor shall prepare a Quarterly Petroleum Operations Costs
statement showing those Petroleum Operations Costs incurred by the
Contractor with respect to the Contract Area, as provided under this Accounting
Procedure.
Any Development and Production Costs shall be separately identified for each
Commercial Field, if such is the case, and the Contractor shall specify the basis
of allocation of shared costs. If the Ministry is not satisfied with the itemization
shown within the categories, the Contractor shall provide a more detailed
breakdown.
Any Exploration Costs shall be shown separately.
The Petroleum Operations Costs statement for each Quarter shall be submitted
to the Ministry no later than a period of thirty (30) days after the end of each
Quarter.
6.4.2
Annual Statement
The Contractor shall prepare an annual Petroleum Operations Costs Statement
containing the following information for the purposes of Articles 9 and 16 of the
Contract:
75
(a)
Petroleum Operations Costs not yet recovered and carried forward from
the previous Calendar Year, if any;
(b)
Petroleum Operations Costs for the Calendar Year in question;
(c)
the quantity and value of Hydrocarbon Production taken by the
Contractor as Cost Recovery Oil under the provisions of Article 7.2 of
the Contract for the Calendar Year in question; and
(d)
Petroleum Operations Costs not yet recovered at the end of the
Calendar Year in question.
The annual Petroleum Operations Costs Statement shall be submitted to the
Ministry no later than a period of forty-five (45) days following the end of each
Calendar Year.
6.5
PRODUCTION SHARING STATEMENT
Within sixty (60) days following the end of each Calendar Year, the Contractor
shall submit to the Ministry with respect to such Calendar Year a Production
sharing statement containing the following information for the purposes of
Article 7 of the Contract:
6.6
(a)
the value of all sales of Hydrocarbons made by the Contractor as from
the Effective Date of the Contract up to the end of the previous Calendar
Year;
(b)
the value of all sales of Hydrocarbons made by the Contractor during the
Calendar Year in question;
(c)
the total of (a) and (b) above at the end of the Calendar Year in
question;
(d)
the accumulated Petroleum Operations Costs as from the Effective Date
of the Contract up to the end of the previous Calendar Year;
(e)
the Petroleum Operations Costs for the Calendar Year in question;
(f)
the total of (d) and (e) above at the end of the Calendar Year in
question;
(g)
quantity and value of the Contractor's share in Hydrocarbons; and
(h)
quantity of State’s share of Hydrocarbons and its value if sold by the
Contractor.
ANNUAL END-OF-YEAR STATEMENT
No later than 31 March of each Calendar Year, the Contractor shall submit to
the Ministry an end-of-year statement, and statement of accounts
corresponding to the previous fiscal Year, and which shall contain the following
information:
76
6.7
(a)
accounting conciliation of the expenses against the approved Annual
Budget;
(b)
accounting conciliation of the expenses with the recoverable costs;
(c)
and accounting conciliation of the expenses with the deductible costs.
ANNUAL BUDGET STATEMENT
The Contractor shall submit to the Ministry an Annual Budget Statement
pursuant to the provisions of Article 4 of the Contract. Such statement shall
distinguish between budgeted Exploration Costs and Development and
Production Costs by Quarter and shall correspond to the individual items of
Petroleum Operations included in the Annual Work Program.
77
ANNEX D - PARENT COMPANY GUARANTEE
This Annex is an integral part of this Contract between the Republic of Equatorial Guinea and the
Contractor.
THIS GUARANTEE is made on this [insert day] of [insert month and year]
BETWEEN:
1. [THE GUARANTOR], a company organized and existing under the laws of [insert
jurisdiction], and having its registered office at [insert address] (the Guarantor); and
2. THE REPUBLIC OF EQUATORIAL GUINEA (the State), represented for the purposes of this
Guarantee by the Ministry of Mines, Industry and Energy (the Ministry).
WHEREAS, the Guarantor is the parent entity of [insert name of Company] organized and
existing under the laws of [insert jurisdiction], and having its registered office at [insert address]
(the Company);
WHEREAS, the Company has entered into a production sharing contract (the Contract) with,
among others, the State in respect of the Contract Area;
WHEREAS, the Company has a Participation Interest under the Contract;
WHEREAS, the State desires that the execution and performance of the Contract by the Company
be guaranteed by the Guarantor and the Guarantor desires to furnish this Guarantee as an
inducement to the State to enter into the Contract and in consideration of the rights and benefits
inuring to the Company thereunder; and
WHEREAS, the Guarantor accepts that it fully understands and assumes the contractual
obligations under the Contract of the Company.
NOW THEREFORE, it is hereby agreed as follows:
1. Definitions and Interpretation
All capitalized words and expressions in this Guarantee have the same meaning as in the
Contract, unless otherwise specified to herein. Article 30 of the Contract is incorporated
herein, mutatis mutandis, by this reference.
2. Scope of this Guarantee
The Guarantor hereby guarantees to the State the timely payment and performance of any
and all indebtedness and obligations whatsoever of the Company to the State arising under
or in relation to the Contract, including the payment of any amounts required to be paid by
the Company to the State when the same become due and payable; provided, however,
that the liability of the Guarantor to the State hereunder shall not exceed the lesser of:
(a)
the liabilities of the Company to the State;
- 78 -
(b)
[insert amount] Dollars ($[insert amount]) during the Exploration Period, as may be
extended in accordance with the Contract; and
(c)
[insert amount] Dollars ($[insert amount]) during the Development and Production
period.
3. Waiver of Notice, Agreement to All Modifications
The Guarantor hereby waives notice of the acceptance of this Guarantee and of the state
of indebtedness of the Company at any time, and expressly agrees to any extensions,
renewals, modifications or acceleration of sums due to the State under the Contract or any
of the terms of the Contract, all without relieving the Guarantor of any liability under this
Guarantee.
4. Absolute and Unconditional Guarantee
The obligations of the Guarantor shall be an absolute, unconditional and (except as
provided in Article 2 above) unlimited guarantee of payment and performance to be
performed strictly in accordance with the terms hereof, and without respect to such
defences as might be available to the Company.
5. No Discharge of Guarantor
The obligations of the Guarantor hereunder shall not in any way be released or otherwise
affected by: a release or surrender by the Company of any collateral or other security it
may hold or hereafter acquire for payment of any obligation hereby guaranteed; by any
change, exchange or alteration of such collateral or other security; by the taking of or the
failure to take any action with respect thereto either against the Company or against the
Guarantor; or by any other circumstance which might otherwise constitute a legal or
equitable discharge or defence of a guarantor.
6. No Prior Action Required
The State shall not be required to make demand for payment or performance first against
the Company or any other Person or to proceed against any collateral or other security
which might be held by the State or otherwise to take any action before resorting to the
Guarantor hereunder.
7. Cumulative Rights
All rights, powers and remedies of the State hereunder shall be cumulative and not
alternative, and shall be in addition to all rights, powers and remedies given to the State by
law or otherwise.
8. Continuing Guarantee
This Guarantee is intended to be and shall be considered as a continuing guarantee of
payment and performance and shall remain in full force and effect for so long as the
Contract and any amendments thereto shall remain outstanding or there shall exist any
liability of the Company to the State thereunder.
9. Notice of Demand
Upon default in the performance of any of the obligations of the Company guaranteed
hereunder, the State or its duly authorized attorney may give written notice to the
Guarantor at its principle office in [insert jurisdiction] of the amount due, and the Guarantor,
within a period
- 79 -
of ten (10) Business Days, will make, or cause to be made, payment of such amount as
notified, in Dollars, at such bank or other place in [insert jurisdiction] as the State shall
designate and without set-off or reduction whatsoever of such payment in respect of any
claim the Parent Company or the Company may then have or thereafter might have.
10. Assignment
The Guarantor shall not in any way effect, or cause or permit to be effected, the
assignment or transfer of any of its obligations hereunder without the express written
consent of the State.
11. Subrogation
Until all indebtedness hereby guaranteed has been paid in full, the Guarantor shall have no
right of subrogation to any security, collateral or other rights which may be held by the
State.
12. Payment of Expenses
The Guarantor shall pay to the State all reasonable costs and expenses, including
attorney's fees, incurred by it in collecting or compromising any indebtedness of the
Company hereby guaranteed or in enforcing the Contract or this Guarantee.
13. Governing Law and Arbitration
This Guarantee shall be governed by and interpreted in accordance with the laws of
Equatorial Guinea.
All disputes or claims arising out of or relating to this Guarantee shall be finally settled by
arbitration, in accordance with the procedure set forth in the Contract; however, if in
addition to the arbitration hereunder an arbitration has also been commenced under the
Contract with respect to obligations hereby guaranteed, the arbitration commenced
hereunder shall be consolidated with the arbitration commenced under the Contract and
the arbitral body appointed hereunder shall be the same arbitral body appointed pursuant
to the Contract. The arbitration shall be conducted in the Spanish and English languages
and the decision shall be final and binding on the parties.
14. Severability of Provisions
In the event that for any reason any provision hereof may prove illegal, unenforceable or
invalid, the validity or enforceability of the remaining provisions hereof shall not be
affected.
15. Confidentiality
The Guarantor agrees to treat this Guarantee and the Contract as confidential and shall
not disclose, willingly or unwillingly, to any third party, except to the extent required by law,
the terms and conditions hereof or thereof without the prior written consent of the State.
- 80 -
IN WITNESS WHEREOF, the Guarantor and the Company execute this Guarantee this [insert
day] day of [insert month and year].
[GUARANTOR]
By: _____________________________
Title: ____________________________
THE REPUBLIC OF EQUATORIAL GUINEA
THE MINISTRY OF MINES, INDUSTRY AND ENERGY
By: ______________________________
Title:_____________________________
- 81 LN356346.18